(a)(1)This section identifies the projects for which a home improvement contract is required, outlines the contract requirements, and lists the items that shall be included in the contract, or may be provided as an attachment.

(2)This section does not apply to service and repair contracts that are subject to Section 7159.10, if the contract for the applicable services complies with Sections 7159.10 to 7159.14, inclusive.

(3)This section does not apply to the sale, installation, and servicing of a fire alarm sold in conjunction with an alarm system, as defined in Section 7590.1, if all costs attributable to making the fire alarm system operable, including sale and installation costs, do not exceed five hundred dollars ($500), and the licensee complies with the requirements set forth in Section 7159.9.

(4)This section does not apply to any costs associated with monitoring a burglar or fire alarm system.

(5)Failure by the licensee, their agent or salesperson, or by a person subject to be licensed under this chapter, to provide the specified information, notices, and disclosures in the contract, or to otherwise fail to comply with any provision of this section, is cause for discipline.

(b)For purposes of this section, home improvement contract means an agreement, whether oral or written, or contained in one or more documents, between a contractor and an owner or between a contractor and a tenant, regardless of the number of residence or dwelling units contained in the building in which the tenant resides, if the work is to be performed in, to, or upon the residence or dwelling unit of the tenant, for the performance of a home improvement, as defined in Section 7151, and includes all labor, services, and materials to be furnished and performed thereunder, if the aggregate contract price specified in one or more improvement contracts, including all labor, services, and materials to be furnished by the contractor, exceeds five hundred dollars ($500). Home improvement contract also means an agreement, whether oral or written, or contained in one or more documents, between a salesperson, whether or not they are a home improvement salesperson, and an owner or a tenant, regardless of the number of residence or dwelling units contained in the building in which the tenant resides, which provides for the sale, installation, or furnishing of home improvement goods or services.

(c)In addition to the specific requirements listed under this section, every home improvement contract and any person subject to licensure under this chapter or their agent or salesperson shall comply with all of the following:

(1)The writing shall be legible.

(2)Any printed form shall be readable. Unless a larger typeface is specified in this article, text in any printed form shall be in at least 10-point typeface and the headings shall be in at least 10-point boldface type.

(3)(A)Before any work is started, the contractor shall give the buyer a copy of the contract signed and dated by both the contractor and the buyer. The buyers receipt of the copy of the contract initiates the buyers rights to cancel the contract pursuant to Sections 1689.5 to 1689.14, inclusive, of the Civil Code.

(B)The contract shall contain on the first page, in a typeface no smaller than that generally used in the body of the document, both of the following:

(i)The date the buyer signed the contract.

(ii)The name and address of the contractor to which the applicable Notice of Cancellation is to be mailed, immediately preceded by a statement advising the buyer that the Notice of Cancellation may be sent to the contractor at the address noted on the contract.

(4)The contract shall include a statement that, upon satisfactory payment being made for any portion of the work performed, the contractor, prior to any further payment being made, shall furnish to the person contracting for the home improvement or swimming pool work a full and unconditional release from any potential lien claimant claim or mechanics lien authorized pursuant to Sections 8400 and 8404 of the Civil Code for that portion of the work for which payment has been made.

(5)A change-order form for changes or extra work shall be incorporated into the contract and shall become part of the contract only if it is in writing and signed by the parties prior to the commencement of any work covered by a change order.

(6)The contract shall contain, in close proximity to the signatures of the owner and contractor, a notice stating that the owner or tenant has the right to require the contractor to have a performance and payment bond.

(7)If the contract provides for a contractor to furnish joint control, the contractor shall not have any financial or other interest in the joint control.

(8)The provisions of this section are not exclusive and do not relieve the contractor from compliance with any other applicable provision of law.

(d)A home improvement contract and any changes to the contract shall be in writing and signed by the parties to the contract prior to the commencement of work covered by the contract or an applicable change order and, except as provided in paragraph (8) of subdivision (a) of Section 7159.5, shall include or comply with all of the following:

(1)The name, business address, and license number of the contractor.

(2)If applicable, the name and registration number of the home improvement salesperson that solicited or negotiated the contract.

(3)The following heading on the contract form that identifies the type of contract in at least 10-point boldface type: Home Improvement.

(4)The following statement in at least 12-point boldface type: You are entitled to a completely filled in copy of this agreement, signed by both you and the contractor, before any work may be started.

(5)The heading: Contract Price, followed by the amount of the contract in dollars and cents.

(6)If a finance charge will be charged, the heading: Finance Charge, followed by the amount in dollars and cents. The finance charge is to be set out separately from the contract amount.

(7)The heading: Description of the Project and Description of the Significant Materials to be Used and Equipment to be Installed, followed by a description of the project and a description of the significant materials to be used and equipment to be installed. For swimming pools, the project description required under this paragraph also shall include a plan and scale drawing showing the shape, size, dimensions, and the construction and equipment specifications.

(8)If a downpayment will be charged, the details of the downpayment shall be expressed in substantially the following form, and shall include the text of the notice as specified in subparagraph (C):

(A)The heading: Downpayment.

(B)A space where the actual downpayment appears.

(C)The following statement in at least 12-point boldface type:

THE DOWNPAYMENT MAY NOT EXCEED $1,000 OR 10 PERCENT OF THE CONTRACT PRICE, WHICHEVER IS LESS.

(9)If payments, other than the downpayment, are to be made before the project is completed, the details of these payments, known as progress payments, shall be expressed in substantially the following form, and shall include the text of the statement as specified in subparagraph (C):

(A)A schedule of progress payments shall be preceded by the heading: Schedule of Progress Payments.

(B)Each progress payment shall be stated in dollars and cents and specifically reference the amount of work or services to be performed and materials and equipment to be supplied.

(C)The section of the contract reserved for the progress payments shall include the following statement in at least 12-point boldface type:

The schedule of progress payments must specifically describe each phase of work, including the type and amount of work or services scheduled to be supplied in each phase, along with the amount of each proposed progress payment. IT IS AGAINST THE LAW FOR A CONTRACTOR TO COLLECT PAYMENT FOR WORK NOT YET COMPLETED, OR FOR MATERIALS NOT YET DELIVERED. HOWEVER, A CONTRACTOR MAY REQUIRE A DOWNPAYMENT.

(10)The contract shall address the commencement of work to be performed in substantially the following form:

(A)A statement that describes what constitutes substantial commencement of work under the contract.

(B)The heading: Approximate Start Date.

(C)The approximate date on which work will be commenced.

(11)The estimated completion date of the work shall be referenced in the contract in substantially the following form:

(A)The heading: Approximate Completion Date.

(B)The approximate date of completion.

(12)If applicable, the heading: List of Documents to be Incorporated into the Contract, followed by the list of documents incorporated into the contract.

(13)The heading: Note About Extra Work and Change Orders, followed by the following statement:

Extra Work and Change Orders become part of the contract once the order is prepared in writing and signed by the parties prior to the commencement of work covered by the new change order. The order must describe the scope of the extra work or change, the cost to be added or subtracted from the contract, and the effect the order will have on the schedule of progress payments.

(e)Except as provided in paragraph (8) of subdivision (a) of Section 7159.5, all of the following notices shall be provided to the owner as part of the contract form as specified or, if otherwise authorized under this subdivision, may be provided as an attachment to the contract:

(1)A notice concerning commercial general liability insurance. This notice may be provided as an attachment to the contract if the contract includes the following statement: A notice concerning commercial general liability insurance is attached to this contract. The notice shall include the heading Commercial General Liability Insurance (CGL), followed by whichever of the following statements is both relevant and correct:

(A)(The name on the license or This contractor) does not carry commercial general liability insurance.

(B)(The name on the license or This contractor) carries commercial general liability insurance written by (the insurance company). You may call (the insurance company) at ____ to check the contractors insurance coverage.

(C)(The name on the license or This contractor) is self-insured.

(D)(The name on the license or This contractor) is a limited liability company that carries liability insurance or maintains other security as required by law. You may call (the insurance company or trust company or bank) at ____ to check on the contractors insurance coverage or security.

(2)A notice concerning workers compensation insurance. This notice may be provided as an attachment to the contract if the contract includes the statement: A notice concerning workers compensation insurance is attached to this contract. The notice shall include the heading Workers Compensation Insurance followed by whichever of the following statements is correct:

(A)(The name on the license or This contractor) has no employees and is exempt from workers compensation requirements.

(B)(The name on the license or This contractor) carries workers compensation insurance for all employees.

(3)A notice that provides the buyer with the following information about the performance of extra or change-order work:

(A)A statement that the buyer may not require a contractor to perform extra or change-order work without providing written authorization prior to the commencement of work covered by the new change order.

(B)A statement informing the buyer that extra work or a change order is not enforceable against a buyer unless the change order also identifies all of the following in writing prior to the commencement of work covered by the new change order:

(i)The scope of work encompassed by the order.

(ii)The amount to be added or subtracted from the contract.

(iii)The effect the order will make in the progress payments or the completion date.

(C)A statement informing the buyer that the contractors failure to comply with the requirements of this paragraph does not preclude the recovery of compensation for work performed based upon legal or equitable remedies designed to prevent unjust enrichment.

(4)A notice with the heading Mechanics Lien Warning written as follows:

MECHANICS LIEN WARNING:

Anyone who helps improve your property, but who is not paid, may record what is called a mechanics lien on your property. A mechanics lien is a claim, like a mortgage or home equity loan, made against your property and recorded with the county recorder.

Even if you pay your contractor in full, unpaid subcontractors, suppliers, and laborers who helped to improve your property may record mechanics liens and sue you in court to foreclose the lien. If a court finds the lien is valid, you could be forced to pay twice or have a court officer sell your home to pay the lien. Liens can also affect your credit.

To preserve their right to record a lien, each subcontractor and material supplier must provide you with a document called a Preliminary Notice. This notice is not a lien. The purpose of the notice is to let you know that the person who sends you the notice has the right to record a lien on your property if they are not paid.

BE CAREFUL. The Preliminary Notice can be sent up to 20 days after the subcontractor starts work or the supplier provides material. This can be a big problem if you pay your contractor before you have received the Preliminary Notices.

You will not get Preliminary Notices from your prime contractor or from laborers who work on your project. The law assumes that you already know they are improving your property.

PROTECT YOURSELF FROM LIENS. You can protect yourself from liens by getting a list from your contractor of all the subcontractors and material suppliers that work on your project. Find out from your contractor when these subcontractors started work and when these suppliers delivered goods or materials. Then wait 20 days, paying attention to the Preliminary Notices you receive.

PAY WITH JOINT CHECKS. One way to protect yourself is to pay with a joint check. When your contractor tells you it is time to pay for the work of a subcontractor or supplier who has provided you with a Preliminary Notice, write a joint check payable to both the contractor and the subcontractor or material supplier.

For other ways to prevent liens, visit CSLBs internet website at www.cslb.ca.gov or call CSLB at 800-321-CSLB (2752).

REMEMBER, IF YOU DO NOTHING, YOU RISK HAVING A LIEN PLACED ON YOUR HOME. This can mean that you may have to pay twice, or face the forced sale of your home to pay what you owe.

(5)The following notice shall be provided in at least 12-point typeface:

Information about the Contractors State License Board (CSLB): CSLB is the state consumer protection agency that licenses and regulates construction contractors.

Contact CSLB for information about the licensed contractor you are considering, including information about disclosable complaints, disciplinary actions, and civil judgments that are reported to CSLB.

Use only licensed contractors. If you file a complaint against a licensed contractor within the legal deadline (usually four years), CSLB has authority to investigate the complaint. If you use an unlicensed contractor, CSLB may not be able to help you resolve your complaint. Your only remedy may be in civil court, and you may be liable for damages arising out of any injuries to the unlicensed contractor or the unlicensed contractors employees.

For more information:

Visit CSLBs internet website at www.cslb.ca.gov

Call CSLB at 800-321-CSLB (2752)

Write CSLB at P.O. Box 26000, Sacramento, CA 95826.

(6)(A)The notice set forth in subparagraph (B) and entitled Five-Day Right to Cancel, or entitled Seven-Day Right to Cancel for contracts with a senior citizen, shall be provided to the buyer unless the contract is:

(i)Negotiated at the contractors place of business.

(ii)Subject to the Seven-Day Right to Cancel, as set forth in paragraph (7).

(iii)Subject to licensure under the Alarm Company Act (Chapter 11.6 (commencing with Section 7590)), provided the alarm company licensee complies with Sections 1689.5, 1689.6, and 1689.7 of the Civil Code, as applicable.

(B)(i)Five-Day Right to Cancel

You, the buyer, have the right to cancel this contract within five business days. You may cancel by emailing, mailing, faxing, or delivering a written notice to the contractor at the contractors place of business by midnight of the fifth business day after you received a signed and dated copy of the contract that includes this notice. Include your name, your address, and the date you received the signed copy of the contract and this notice.

If you cancel, the contractor must return to you anything you paid within 10 days of receiving the notice of cancellation. For your part, you must make available to the contractor at your residence, in substantially as good condition as you received them, goods delivered to you under this contract or sale. Or, you may, if you wish, comply with the contractors instructions on how to return the goods at the contractors expense and risk. If you do make the goods available to the contractor and the contractor does not pick them up within 20 days of the date of your notice of cancellation, you may keep them without any further obligation. If you fail to make the goods available to the contractor, or if you agree to return the goods to the contractor and fail to do so, then you remain liable for performance of all obligations under the contract.

(ii)References to five and fifth in the notice set forth in clause (i) shall be changed to seven and seventh respectively, for a buyer who is a senior citizen.

(C)The notice required by this paragraph shall comply with all of the following:

(i)The text of the notice is at least 12-point boldface type.

(ii)The notice is in immediate proximity to a space reserved for the owners signature.

(iii)The owner acknowledges receipt of the notice by signing and dating the notice form in the signature space.

(iv)The notice is written in the same language, e.g., Spanish, as that principally used in any oral sales presentation.

(v)The notice may be attached to the contract if the contract includes, in at least 12-point boldface type, a checkbox with one of the following statements, as applicable:

(I)For a contract with a senior citizen: The law requires that the contractor give you a notice explaining your right to cancel. Initial the checkbox if the contractor has given you a Notice of the Seven-Day Right to Cancel.

(II)For all other contracts: The law requires that the contractor give you a notice explaining your right to cancel. Initial the checkbox if the contractor has given you a Notice of the Five-Day Right to Cancel.

(vi)(I)The notice shall be accompanied by a completed form in duplicate, captioned Notice of Cancellation, which also shall be attached to the agreement or offer to purchase and be easily detachable, and which shall contain the following statement written in the same language, e.g., Spanish, as used in the contract:

You may cancel this transaction, without any penalty or obligation, within five business days from the above date.

If you cancel, any property traded in, any payments made by you under the contract or sale, and any negotiable instrument executed by you will be returned within 10 days following receipt by the seller of your cancellation notice, and any security interest arising out of the transaction will be canceled.

If you cancel, you must make available to the seller at your residence, in substantially as good condition as when received, any goods delivered to you under this contract or sale, or you may, if you wish, comply with the instructions of the seller regarding the return shipment of the goods at the sellers expense and risk.

If you do make the goods available to the seller and the seller does not pick them up within 20 days of the date of your notice of cancellation, you may retain or dispose of the goods without any further obligation. If you fail to make the goods available to the seller, or if you agree to return the goods to the seller and fail to do so, then you remain liable for performance of all obligations under the contract.

(II)The reference to five five in the statement set forth in subclause (I) shall be changed to seven for a buyer who is a senior citizen.

(7)(A)The following notice entitled Seven-Day Right to Cancel shall be provided to the buyer for any contract that is written for the repair or restoration of residential premises damaged by any sudden or catastrophic event for which a state of emergency has been declared by the President of the United States or the Governor, or for which a local emergency has been declared by the executive officer or governing body of any city, county, or city and county:

Seven-Day Right to Cancel

You, the buyer, have the right to cancel this contract within seven business days. You may cancel by emailing, mailing, faxing, or delivering a written notice to the contractor at the contractors place of business by midnight of the seventh business day after you received a signed and dated copy of the contract that includes this notice. Include your name, your address, and the date you received the signed copy of the contract and this notice.

If you cancel, the contractor must return to you anything you paid within 10 days of receiving the notice of cancellation. For your part, you must make available to the contractor at your residence, in substantially as good condition as you received them, goods delivered to you under this contract or sale. Or, you may, if you wish, comply with the contractors instructions on how to return the goods at the contractors expense and risk. If you do make the goods available to the contractor and the contractor does not pick them up within 20 days of the date of your notice of cancellation, you may keep them without any further obligation. If you fail to make the goods available to the contractor, or if you agree to return the goods to the contractor and fail to do so, then you remain liable for performance of all obligations under the contract.

(B)The Seven-Day Right to Cancel notice required by this subdivision shall comply with all of the following:

(i)The text of the notice is at least 12-point boldface type.

(ii)The notice is in immediate proximity to a space reserved for the owners signature.

(iii)The owner acknowledges receipt of the notice by signing and dating the notice form in the signature space.

(iv)The notice is written in the same language, e.g., Spanish, as that principally used in any oral sales presentation.

(v)The notice may be attached to the contract if the contract includes, in at least 12-point boldface type, a checkbox with the following statement: The law requires that the contractor give you a notice explaining your right to cancel. Initial the checkbox if the contractor has given you a Notice of the Seven-Day Right to Cancel.

(vi)The notice shall be accompanied by a completed form in duplicate, captioned Notice of Cancellation, which shall also be attached to the agreement or offer to purchase and be easily detachable, and which shall contain the following statement written in the same language, e.g., Spanish, as used in the contract:

You may cancel this transaction, without any penalty or obligation, within seven business days from the above date.

If you cancel, any property traded in, any payments made by you under the contract or sale, and any negotiable instrument executed by you will be returned within 10 days following receipt by the seller of your cancellation notice, and any security interest arising out of the transaction will be canceled.

If you cancel, you must make available to the seller at your residence, in substantially as good condition as when received, any goods delivered to you under this contract or sale, or you may, if you wish, comply with the instructions of the seller regarding the return shipment of the goods at the sellers expense and risk.

If you do make the goods available to the seller and the seller does not pick them up within 20 days of the date of your notice of cancellation, you may retain or dispose of the goods without any further obligation. If you fail to make the goods available to the seller, or if you agree to return the goods to the seller and fail to do so, then you remain liable for performance of all obligations under the contract.

(f)The five-day right to cancel added by the act that amended paragraph (6) of subdivision (e) shall apply to contracts entered into on or after January 1, 2021.

(g)The five-day and seven-day rights to cancel added by the act in the 202324 Regular Session of the Legislature that amended paragraph (6) of subdivision (e) shall apply to contracts entered into on or after January 1, 2025.

This section applies to all home improvement contracts, as defined in Section 7151.2, between an owner or tenant and a contractor, whether a general contractor or a specialty contractor, that is licensed or subject to be licensed pursuant to this chapter with regard to the transaction.

(a)Failure by the licensee or a person subject to be licensed under this chapter, or by their agent or salesperson, to comply with the following provisions is cause for discipline:

(1)The contract shall be in writing and shall include the agreed contract amount in dollars and cents. The contract amount shall include the entire cost of the contract, including profit, labor, and materials, but excluding finance charges.

(2)If there is a separate finance charge between the contractor and the person contracting for home improvement, the finance charge shall be set out separately from the contract amount.

(3)If a downpayment will be charged, the downpayment shall not exceed one thousand dollars ($1,000) or 10 percent of the contract amount, whichever amount is less.

(4)If, in addition to a downpayment, the contract provides for payments to be made prior to completion of the work, the contract shall include a schedule of payments in dollars and cents specifically referencing the amount of work or services to be performed and any materials and equipment to be supplied.

(5)Except for a downpayment, the contractor shall neither request nor accept payment that exceeds the value of the work performed or material delivered. The prohibition prescribed by this paragraph extends to advance payment in whole or in part from any lender or financier for the performance or sale of home improvement goods or services.

(6)Upon any payment by the person contracting for home improvement, and prior to any further payment being made, the contractor shall, if requested, obtain and furnish to the person a full and unconditional release from any potential lien claimant claim or mechanics lien authorized pursuant to Sections 8400 and 8404 of the Civil Code for any portion of the work for which payment has been made. The person contracting for home improvement may withhold all further payments until these releases are furnished.

(7)If the contract provides for a payment of a salespersons commission out of the contract price, that payment shall be made on a pro rata basis in proportion to the schedule of payments made to the contractor by the disbursing party in accordance with paragraph (4).

(8)A contractor furnishing a performance and payment bond, lien and completion bond, or a bond equivalent or joint control approved by the registrar covering full performance and payment is exempt from paragraphs (3), (4), and (5), and need not include, as part of the contract, the statement regarding the downpayment specified in subparagraph (C) of paragraph (8) of subdivision (d) of Section 7159, the details and statement regarding progress payments specified in paragraph (9) of subdivision (d) of Section 7159, or the Mechanics Lien Warning specified in paragraph (4) of subdivision (e) of Section 7159. A contractor furnishing these bonds, bond equivalents, or a joint control approved by the registrar may accept payment prior to completion. If the contract provides for a contractor to furnish joint control, the contractor shall not have any financial or other interest in the joint control. Notwithstanding any other law, a licensee shall be licensed in this state in an active status for not less than two years prior to submitting an Application for Approval of Blanket Performance and Payment Bond as provided in Section 858.2 of Title 16 of the California Code of Regulations as it read on January 1, 2016.

(9)The contractor shall not request or accept full payment from a finance lender, as defined in Section 22009 of the Financial Code, until the contractor has received a written confirmation from the owner acknowledging all of the following: lender or financier until the following has occurred:

(A)The The contractor, lender, or financier has received written confirmation from the owner or tenant that the home improvement project has been completed in accordance with the contract. contract and is operational or fit for its intended use.

(B)Final The lender has confirmed with the contractor that final approval has been provided by all permitting agencies.

(b)(1)A violation of paragraph (1), (3), or (5) of subdivision (a) by a licensee or a person subject to be licensed under this chapter, or by their agent or salesperson, is a misdemeanor punishable by a fine of not less than one hundred dollars ($100) nor more than five thousand dollars ($5,000), or by imprisonment in a county jail not exceeding one year, or by both that fine and imprisonment. If a violation occurs in a location damaged by a natural disaster for which a state of emergency is proclaimed by the Governor pursuant to Section 8625 of the Government Code or for which an emergency or major disaster is declared by the President of the United States, the court shall impose the maximum fine.

(2)(A)An indictment or information against a person who is not licensed but who is required to be licensed under this chapter shall be brought, or a criminal complaint filed, for a violation of this section, in accordance with paragraph (4) of subdivision (d) of Section 802 of the Penal Code, within four years from the date of the contract or, if the contract is not reduced to writing, from the date the buyer makes the first payment to the contractor.

(B)An indictment or information against a person who is licensed under this chapter shall be brought, or a criminal complaint filed, for a violation of this section, in accordance with paragraph (2) of subdivision (d) of Section 802 of the Penal Code, within two years from the date of the contract or, if the contract is not reduced to writing, from the date the buyer makes the first payment to the contractor.

(C)The limitations on actions in this subdivision shall not apply to any administrative action filed against a licensed contractor.

(c)(1)Any person who violates this section as part of a plan or scheme to defraud an owner or tenant of a residential or nonresidential structure, including a mobilehome or manufactured home, in connection with the offer or performance of repairs to the structure for damage caused by a natural disaster, shall be ordered by the court to make full restitution to the victim based on the persons ability to pay, defined as the overall capability of the defendant to reimburse the costs, or a portion of the costs, including consideration of, but not limited to, all of the following:

(A)The defendants present financial position.

(B)The defendants reasonably discernible future financial position, provided that the court shall not consider a period of more than one year from the date of the hearing for purposes of determining the reasonably discernible future financial position of the defendant.

(C)The likelihood that the defendant will be able to obtain employment within one year from the date of the hearing.

(D)Any other factor that may bear upon the defendants financial capability to reimburse the county for costs.

(2)In addition to full restitution, and imprisonment authorized by this section, the court may impose a fine of not less than five hundred dollars ($500) nor more than twenty-five thousand dollars ($25,000), based upon the defendants ability to pay. This subdivision applies to natural disasters for which a state of emergency is proclaimed by the Governor pursuant to Section 8625 of the Government Code, or for which an emergency or major disaster is declared by the President of the United States.

(d)This section shall become operative on July 1, 2021.

(a)(1)Except for a contract written pursuant to Section 7151.2 or 7159.10 of the Business and Professions Code, in addition to any other right to revoke an offer, the buyer has the right to cancel a home solicitation contract or offer until midnight of the fifth third business day, or until midnight of the seventh fifth business day if the buyer is a senior citizen, after the day on which the buyer signs an agreement or offer to purchase which complies with Section 1689.7.

(2)In addition to any other right to revoke an offer, the buyer has the right to cancel a home solicitation contract written pursuant to Section 7151.2 of the Business and Professions Code until Code, or a home improvement loan as defined in Section 22205 of the Financial Code, until midnight of the fifth business day, or until midnight of the seventh business day if the buyer is a senior citizen, after the buyer receives a signed and dated copy of the contract or offer to purchase that complies with Section 1689.7 of this code.

(3)(A)In addition to any other right to revoke an offer, the buyer has the right to cancel a home solicitation contract or offer to purchase written pursuant to Section 7159.10 of the Business and Professions Code, until the buyer receives a signed and dated copy of a service and repair contract that complies with the contract requirements specified in Section 7159.10 of the Business and Professions Code and the work commences.

(B)For any contract written pursuant to Section 7159.10 of the Business and Professions Code, or otherwise presented to the buyer as a service and repair contract, unless all of the conforming requirements listed under subdivision (a) of that section are met, the requirements set forth under Section 7159 of the Business and Professions Code shall be applicable, regardless of the aggregate contract price, including the right to cancel as set forth under this section.

(4)The five-day right to cancel added by the act that amended paragraphs (1) and (2) shall apply to contracts entered into, or offers to purchase conveyed, on or after January 1, 2021.

(5)The five-day and seven-day rights to cancel added by the act amending paragraphs (1) and paragraph (2) in the 202324 Regular Session of the Legislature shall apply to contracts entered into, or offers to purchase conveyed, on or after January 1, 2025.

(b)In addition to any other right to revoke an offer, any buyer has the right to cancel a home solicitation contract or offer for the purchase of a personal emergency response unit until midnight of the seventh business day after the day on which the buyer signs an agreement or offer to purchase which complies with Section 1689.7. This subdivision shall not apply to a personal emergency response unit installed with, and as part of, a home security alarm system subject to the Alarm Company Act (Chapter 11.6 (commencing with Section 7590) of Division 3 of the Business and Professions Code) which has two or more stationary protective devices used to enunciate an intrusion or fire and is installed by an alarm company operator operating under a current license issued pursuant to the Alarm Company Act, which shall instead be subject to subdivision (a).

(c)In addition to any other right to revoke an offer, a buyer has the right to cancel a home solicitation contract or offer for the repair or restoration of residential premises damaged by a disaster that was not void pursuant to Section 1689.14, until midnight of the seventh business day after the buyer signs and dates the contract unless the provisions of Section 1689.15 are applicable.

(d)Cancellation occurs when the buyer gives written notice of cancellation to the seller at the address specified in the agreement or offer.

(e)Notice of cancellation, if given by mail, is effective when deposited in the mail properly addressed with postage prepaid.

(f)Notice of cancellation given by the buyer need not take the particular form as provided with the contract or offer to purchase and, however expressed, is effective if it indicates the intention of the buyer not to be bound by the home solicitation contract or offer.

(g)Personal emergency response unit, for purposes of this section, means an in-home radio transmitter device or two-way radio device generally, but not exclusively, worn on a neckchain, wrist strap, or clipped to clothing, and connected to a telephone line through which a monitoring station is alerted of an emergency and emergency assistance is summoned.

(a)(1)Except for contracts written pursuant to Sections 7151.2 and 7159.10 of the Business and Professions Code, in a home solicitation contract or offer, the buyers agreement or offer to purchase shall be written in the same language, e.g., Spanish, as principally used in the oral sales presentation, shall be dated, shall be signed by the buyer, and except as provided in paragraph (2), shall contain in immediate proximity to the space reserved for the buyers signature, a conspicuous statement in a size equal to at least 10-point boldface type, as follows:

(A)For a buyer who is a senior citizen:You, the buyer, may cancel this transaction at any time prior to midnight of the seventh fifth business day after the date of this transaction. See the attached notice of cancellation form for an explanation of this right.

(B)For all other buyers:You, the buyer, may cancel this transaction at any time prior to midnight of the fifth third business day after the date of this transaction. See the attached notice of cancellation form for an explanation of this right.

(2)The statement required pursuant to this subdivision for a home solicitation contract or offer for the purchase of a personal emergency response unit, as defined in Section 1689.6, that is not installed with and as part of a home security alarm system subject to the Alarm Company Act (Chapter 11.6 (commencing with Section 7590) of Division 3 of the Business and Professions Code) that has two or more stationary protective devices used to enunciate an intrusion or fire and is installed by an alarm company operator operating under a current license issued pursuant to the Alarm Company Act, is as follows: You, the buyer, may cancel this transaction at any time prior to midnight of the seventh business day after the date of this transaction. See the attached notice of cancellation form for an explanation of this right.

(3)Except for contracts written pursuant to Sections 7151.2 and 7159.10 of the Business and Professions Code, the statement required pursuant to this subdivision for the repair or restoration of residential premises damaged by a disaster pursuant to subdivision (c) of Section 1689.6 is as follows:You, the buyer, may cancel this transaction at any time prior to midnight of the seventh business day after the date of this transaction. See the attached notice of cancellation form for an explanation of this right.

(4)(A)A home solicitation contract written pursuant to Section 7151.2 of the Business and Professions Code shall be written in the same language, e.g., Spanish, as principally used in the oral sales presentation. The contract, or an attachment to the contract that is subject to Section 7159 of the Business and Professions Code shall include in immediate proximity to the space reserved for the buyers signature, the following statement in a size equal to at least 12-point boldface type, which shall be dated and signed by the buyer:

Five-Day Right to Cancel

You, the buyer, have the right to cancel this contract within five business days. You may cancel by e-mailing, mailing, faxing, or delivering a written notice to the contractor at the contractors place of business by midnight of the fifth business day after you received a signed and dated copy of the contract that includes this notice. Include your name, your address, and the date you received the signed copy of the contract and this notice.

If you cancel, the contractor must return to you anything you paid within 10 days of receiving the notice of cancellation. For your part, you must make available to the contractor at your residence, in substantially as good condition as you received it, any goods delivered to you under this contract or sale. Or, you may, if you wish, comply with the contractors instructions on how to return the goods at the contractors expense and risk. If you do make the goods available to the contractor and the contractor does not pick them up within 20 days of the date of your notice of cancellation, you may keep them without any further obligation. If you fail to make the goods available to the contractor, or if you agree to return the goods to the contractor and fail to do so, then you remain liable for performance of all obligations under the contract.

(B)References to five and fifth in the statement set forth in subparagraph (A) shall be changed to seven and seventh, respectively, for a buyer who is a senior citizen.

(b)The agreement or offer to purchase shall contain on the first page, in a type size no smaller than that generally used in the body of the document, the following: (1) the name and address of the seller to which the notice is to be mailed, and (2) the date the buyer signed the agreement or offer to purchase.

(c)(1)Except for contracts written pursuant to Sections 7151.2 and 7159.10 of the Business and Professions Code, or except as provided in subdivision (d), the agreement or offer to purchase shall be accompanied by a completed form in duplicate, captioned Notice of Cancellation which shall be attached to the agreement or offer to purchase and be easily detachable, and which shall contain in type of at least 10-point the following statement written in the same language, e.g., Spanish, as used in the contract:

You may cancel this transaction, without any penalty or obligation, within five three business days from the above date.

If you cancel, any property traded in, any payments made by you under the contract or sale, and any negotiable instrument executed by you will be returned within 10 days following receipt by the seller of your cancellation notice, and any security interest arising out of the transaction will be canceled.

If you cancel, you must make available to the seller at your residence, in substantially as good condition as when received, any goods delivered to you under this contract or sale, or you may, if you wish, comply with the instructions of the seller regarding the return shipment of the goods at the sellers expense and risk.

If you do make the goods available to the seller and the seller does not pick them up within 20 days of the date of your notice of cancellation, you may retain or dispose of the goods without any further obligation. If you fail to make the goods available to the seller, or if you agree to return the goods to the seller and fail to do so, then you remain liable for performance of all obligations under the contract.

(2)The reference to five three in the statement set forth in paragraph (1) shall be changed to seven five for a buyer who is a senior citizen.

(d)Any agreement or offer to purchase a personal emergency response unit, as defined in Section 1689.6, which is not installed with and as part of a home security alarm system subject to the Alarm Company Act which has two or more stationary protective devices used to enunciate an intrusion or fire and is installed by an alarm company operator operating under a current license issued pursuant to the Alarm Company Act, shall be subject to the requirements of subdivision (c), and shall be accompanied by the Notice of Cancellation required by subdivision (c), except that the first paragraph of that notice shall be deleted and replaced with the following paragraph:

You may cancel this transaction, without any penalty or obligation, within seven business days from the above date.

(e)A home solicitation contract written pursuant to Section 7151.2 of the Business and Professions Code for the repair or restoration of residential premises damaged by a disaster that is subject to subdivision (c) of Section 1689.6, shall be written in the same language, e.g., Spanish, as principally used in the oral sales presentation. The contract, or an attachment to the contract that is subject to Section 7159 of the Business and Professions Code shall include, in immediate proximity to the space reserved for the buyers signature, the following statement in a size equal to at least 12-point boldface type, which shall be signed and dated by the buyer:

Seven-Day Right to Cancel

You, the buyer, have the right to cancel this contract within seven business days. You may cancel by e-mailing, mailing, faxing, or delivering a written notice to the contractor at the contractors place of business by midnight of the seventh business day after you received a signed and dated copy of the contract that includes this notice. Include your name, your address, and the date you received the signed copy of the contract and this notice.

If you cancel, the contractor must return to you anything you paid within 10 days of receiving the notice of cancellation. For your part, you must make available to the contractor at your residence, in substantially as good condition as you received it, any goods delivered to you under this contract or sale. Or, you may, if you wish, comply with the contractors instructions on how to return the goods at the contractors expense and risk. If you do make the goods available to the contractor and the contractor does not pick them up within 20 days of the date of your notice of cancellation, you may keep them without any further obligation. If you fail to make the goods available to the contractor, or if you agree to return the goods to the contractor and fail to do so, then you remain liable for performance of all obligations under the contract.

(f)The seller shall provide the buyer with a copy of the contract or offer to purchase and the attached notice of cancellation, and shall inform the buyer orally of the buyers right to cancel and the requirement that cancellation be in writing, at the time the home solicitation contract or offer is executed.

(g)Until the seller has complied with this section the buyer may cancel the home solicitation contract or offer.

(h)Contract or sale as used in subdivision (c) means home solicitation contract or offer as defined by Section 1689.5.

(i)The five-day right to cancel added by the act that added subparagraph (A) to paragraph (1) and subparagraph (B) to paragraph (4) of subdivision (a), and paragraph (2) to subdivision (c) applies to contracts, or offers to purchase conveyed, entered into, on or after January 1, 2021.

Sections 1689.5, 1689.6, 1689.7, 1689.10, 1689.12, and 1689.14 do not apply to a contract that meets all of the following requirements:

(a)The contract is initiated by the buyer or the buyers agent or insurance representative.

(b)The contract is executed in connection with making of emergency or immediately necessary repairs that are necessary for the immediate protection of persons or real or personal property.

(c)(1)The buyer gives the seller a separate statement that is dated and signed that describes the situation that requires immediate remedy, and expressly acknowledges and waives the right to cancel the sale within five or seven business days, whichever applies. the applicable time period.

(2)The waiver of the five-day right to cancel added by the act that amended paragraph (1) shall apply to contracts entered into, or offers to purchase conveyed, on or after January 1, 2021.

(3)The waiver of the five-day and seven-day rights applicable time period to exercise ones right to cancel a sale, as specified, and as added by the act in the 202324 Regular Session of the Legislature that amended paragraph (1) shall apply to contracts entered into, or offers to purchase conveyed, on or after January 1, 2025.

(a)Home improvement loan means a consumer loan issued by a finance lender subject to this division, the proceeds of which will be disbursed to a contractor in connection with a home solicitation contract, as defined in Section 1689.5 of the Civil Code, improvement contract negotiated outside the contractors place of business to finance a home improvement, as defined in Section 7151 of the Business and Professions Code.

(b)Home improvement loan shall not include a PACE assessment, as defined in Section 22015.

(a)(1)Before a consumer executes a contract for a home improvement loan to pay for a home improvement and before the right-to-cancel time period expires for a home improvement contract contract, as defined in Section 7159 of the Business and Professions Code, that is being financed by a home improvement loan, the finance lender shall do all of the following:

(A)Obtain a copy of the home improvement contract for the home improvement that is being financed by the home improvement loan.

(B)Complete and document a telephone call telephone, video, or digital call pursuant to paragraphs (2) and (3) to make oral confirmations about all of the following:

(i)All owners of the property have received a copy of the home improvement loan contract, with the key terms completed, the financing estimate and disclosure form required under the federal Truth in Lending Act, and the right to cancel form.

(ii)The key terms of the home improvement loan contract, in plain language, with the consumer on the call or to a verified authorized representative of the designated by the consumer on the call. The finance lender shall obtain acknowledgment of the key terms from the consumer on the call to whom the oral confirmation is given.

(2)(A)At the commencement of the oral confirmation, the finance lender shall ask if the consumer on the call would prefer to communicate during the oral confirmation primarily in a language other than English that is specified in Section 1632 of the Civil Code. If the preferred language is supported by the finance lender, the oral confirmation shall be given in that primary language, except where the consumer on the call chooses to communicate through their own interpreter. If the preferred language is not supported and an interpreter is not chosen by the consumer on the call, the home improvement loan contract shall not proceed. finance lender shall not execute the home improvement loan contract with the consumer.

(B)The oral confirmation required pursuant to subparagraph (A) (B) of paragraph (1) shall include, but is not limited to, all of the following information:

(i)The consumer on the call has the right to have other persons present for the call, and an inquiry as to whether the consumer requests to exercise the right to include anyone else on the call. This shall occur at the onset of the call, after the determination of the preferred language of communication. The contractor or contractor salesperson, or both, for the home improvements being financed by the loan shall not be present during or participate in the call. A third party shall not be allowed to participate in the call unless expressly authorized by the consumer.

(ii)The consumer on the call is informed that they should review the home improvement loan and financing estimate and disclosure form with all other owners of the property.

(iii)The home improvements being installed that are being financed by the home improvement loan, including, but not limited to, the description of the home improvements as described in the home improvement contract.

(iv)The key terms of the home improvement loan.

(v)Confirmation of the consumers gross monthly household income and ability to pay the monthly payment amount and total cost.

(vi)The consumer understands that any estimates of cost savings from the home improvements are not guaranteed and may be unreliable.

(vii)Whether the property will be subject to a financing statement filing requirement, as specified in Section 9501 of the Commercial Code, during the term of the loan contract and that the obligations under the loan contract may be required to be paid in full before the property owner sells or refinances the property.

(3)The finance lender shall maintain a recording of the oral confirmation telephone telephone, video, or digital call for at least five years after the loan term ends and shall make it available to the consumer upon request.

(b)If the oral confirmation required by this section was conducted primarily in a language other than English that is specified in Section 1632 of the Civil Code, the finance lender shall deliver in writing in the language used during the oral confirmation in the disclosures and contract or agreement required by law, including, but not limited to, all of the following:

(1)The loan contract.

(2)The right to cancel form.

(3)The financing estimate and disclosure form required under the federal Truth in Lending Act.

(c)As used in this section:

(1)Home improvement has the same meaning as defined in Section 7151 of the Business and Professions Code.

(2)Home improvement contract has the same meaning as defined in Section 7151.2 Section 7159 of the Business and Professions Code.

(3)Key terms means the terms of the home improvement loan, including what home improvements are being financed, the name of the contractor who will receive the loan proceeds, the loan term or period of time for repayment, total cost, monthly payment amounts, finance charge, and due dates, whether the amount of monthly payments due will change during the term of the loan, annual percentage rate of interest, how late fees may be incurred, how payments more than the minimum payment will be applied, whether there are any prepayment penalties, and when the first payment is due.

(4)Their own interpreter means a person, who is not a minor, who is able to speak fluently and read with full understanding both the English language and any of the languages specified in Section 1632 of the Civil Code, and who is not employed by, and whose services are not made available through, the finance lender or the contractor.

(a)A finance lender that engages in offering or providing a home improvement loan shall make available to the consumer or property owner, or both, upon request, information in the control or possession of the lender concerning the home improvement loan that was provided to the consumer to finance the home improvement contract, including information relating to any transaction, series of transactions, or to the account, including costs, charges, and payment history.

(b)A finance lender shall comply with the requirements of this section for any written request for information from a consumer or their verified representative that includes the name of the consumer, information that enables the lender to identify the consumers account, and states the information the consumer is requesting.

(c)A finance lender shall provide to the consumer or their verified authorized representative, upon request, any of the following documentation:

(1)Financing application executed information provided by consumer.

(2)Financing agreement and disclosures, including all certificates, disclosures, and contracts associated with the account, home improvement loan, and including all any signed or initialed copies.

(3)A copy of the home improvement contract obtained by the finance lender for the financed work, including all signed copies. work.

(4)Completion certificates or other evidence that performance of a home improvement is complete or satisfactorily concluded, including all any signed copies.

(5)Electronic Documentation of any electronic signatures obtained in connection with the home improvement loan, including electronic certificates, including verifications of all signatures that were obtained electronically, electronic signature envelopes, or audit trails.

(6)Documentation of all payments to contractor.

(7)Financing estimate and disclosures.

(8)An accounting from date of original transaction to the present.

(9)If secured by a financing statement, as described in Section 9501 of the Commercial Code, the finance lender shall provide that financing statement and the list of collateral or statement of account, or both, under Section 9210 of the Commercial Code.

(10)Recordings of all oral confirmation telephone calls with the consumer. consumer or their verified representative.

(d)A finance lender has a duty to maintain each of the records specified in subdivision (c) relating to any transaction for five years from the date that the financed amount is remitted to the contractor, or five years after the loan is repaid in full, whichever is later.

(e)A finance lender, by written notice provided to a consumer, may establish an address that a consumer must use to request information in accordance with the procedures in this section.

(f)No later than 30 business days after the finance lender receives the request for information, the finance lender shall do one of the following:

(1)Provide the consumer with the requested information and contact information, including a telephone number, for further assistance in writing.

(2)Conduct a reasonable search for the requested information and provide the consumer with a written notification that states that the lender has determined that the requested information is not available to the lender. That notification shall also identify the basis for the lenders determination, and provide contact information, including a telephone number, for further assistance.

(g)A finance lender, as a condition of responding to an information request, shall not charge a fee, or require a consumer to make any payment that may be owed on the consumers account, or impose any other requirement.

(h)As used in this section, consumer has the same meaning as defined in Section 4052.

(a)A finance lender who makes a home improvement loan shall not release funds to the home improvement contractor, other than the downpayment allowed under Section 7159 of the Business and Professions Code or those payments consistent with paragraphs (4) and (5) of subdivision (a) of Section 7159.5 of the Business and Professions Code, unless the property the following conditions have occurred:

(1)The property owner has certified orally, by means of a both orally in a confirmation telephone call and a through a written confirmation signed by the property owner, that the home improvements for which the payment is being made have been completed in accordance with the contract.

(2)Upon satisfaction of the condition specified in paragraph (1), no more than 85 percent of the funds shall be released to the home improvement contractor, and no payment shall be sought from the consumer, until the contractor. The balance of funds to be paid to the contractor shall not be released until the finance lender has confirmed that all home improvements have been given final approval by all permitting agencies and are operational. operational or fit for its intended use. A solar energy system shall not be deemed operational until after the property owner confirms the utility supplying electricity has been connected to the solar energy system, the utility supplying electricity grants permission to operate the solar energy system, and the property owner confirms the solar energy system is functioning.

(b)Payment shall not be received from the consumer on the home improvement loan until the conditions set forth in paragraph (2) of subdivision (a) have been satisfied.

(c)As used in this section,solar section, solar energy system has the same meaning as defined in Section 7151 of the Business and Professions Code.

(a)(1)This section identifies the projects for which a home improvement contract is required, outlines the contract requirements, and lists the items that shall be included in the contract, or may be provided as an attachment.

(2)This section does not apply to service and repair contracts that are subject to Section 7159.10, if the contract for the applicable services complies with Sections 7159.10 to 7159.14, inclusive.

(3)This section does not apply to the sale, installation, and servicing of a fire alarm sold in conjunction with an alarm system, as defined in Section 7590.1, if all costs attributable to making the fire alarm system operable, including sale and installation costs, do not exceed five hundred dollars ($500), and the licensee complies with the requirements set forth in Section 7159.9.

(4)This section does not apply to any costs associated with monitoring a burglar or fire alarm system.

(5)Failure by the licensee, their agent or salesperson, or by a person subject to be licensed under this chapter, to provide the specified information, notices, and disclosures in the contract, or to otherwise fail to comply with any provision of this section, is cause for discipline.

(b)For purposes of this section, home improvement contract means an agreement, whether oral or written, or contained in one or more documents, between a contractor and an owner or between a contractor and a tenant, regardless of the number of residence or dwelling units contained in the building in which the tenant resides, if the work is to be performed in, to, or upon the residence or dwelling unit of the tenant, for the performance of a home improvement, as defined in Section 7151, and includes all labor, services, and materials to be furnished and performed thereunder, if the aggregate contract price specified in one or more improvement contracts, including all labor, services, and materials to be furnished by the contractor, exceeds five hundred dollars ($500). Home improvement contract also means an agreement, whether oral or written, or contained in one or more documents, between a salesperson, whether or not they are a home improvement salesperson, and an owner or a tenant, regardless of the number of residence or dwelling units contained in the building in which the tenant resides, which provides for the sale, installation, or furnishing of home improvement goods or services.

(c)In addition to the specific requirements listed under this section, every home improvement contract and any person subject to licensure under this chapter or their agent or salesperson shall comply with all of the following:

(1)The writing shall be legible.

(2)Any printed form shall be readable. Unless a larger typeface is specified in this article, text in any printed form shall be in at least 10-point typeface and the headings shall be in at least 10-point boldface type.

(3)(A)Before any work is started, the contractor shall give the buyer a copy of the contract signed and dated by both the contractor and the buyer. The buyers receipt of the copy of the contract initiates the buyers rights to cancel the contract pursuant to Sections 1689.5 to 1689.14, inclusive, of the Civil Code.

(B)The contract shall contain on the first page, in a typeface no smaller than that generally used in the body of the document, both of the following:

(i)The date the buyer signed the contract.

(ii)The name and address of the contractor to which the applicable Notice of Cancellation is to be mailed, immediately preceded by a statement advising the buyer that the Notice of Cancellation may be sent to the contractor at the address noted on the contract.

(4)The contract shall include a statement that, upon satisfactory payment being made for any portion of the work performed, the contractor, prior to any further payment being made, shall furnish to the person contracting for the home improvement or swimming pool work a full and unconditional release from any potential lien claimant claim or mechanics lien authorized pursuant to Sections 8400 and 8404 of the Civil Code for that portion of the work for which payment has been made.

(5)A change-order form for changes or extra work shall be incorporated into the contract and shall become part of the contract only if it is in writing and signed by the parties prior to the commencement of any work covered by a change order.

(6)The contract shall contain, in close proximity to the signatures of the owner and contractor, a notice stating that the owner or tenant has the right to require the contractor to have a performance and payment bond.

(7)If the contract provides for a contractor to furnish joint control, the contractor shall not have any financial or other interest in the joint control.

(8)The provisions of this section are not exclusive and do not relieve the contractor from compliance with any other applicable provision of law.

(d)A home improvement contract and any changes to the contract shall be in writing and signed by the parties to the contract prior to the commencement of work covered by the contract or an applicable change order and, except as provided in paragraph (8) of subdivision (a) of Section 7159.5, shall include or comply with all of the following:

(1)The name, business address, and license number of the contractor.

(2)If applicable, the name and registration number of the home improvement salesperson that solicited or negotiated the contract.

(3)The following heading on the contract form that identifies the type of contract in at least 10-point boldface type: Home Improvement.

(4)The following statement in at least 12-point boldface type: You are entitled to a completely filled in copy of this agreement, signed by both you and the contractor, before any work may be started.

(5)The heading: Contract Price, followed by the amount of the contract in dollars and cents.

(6)If a finance charge will be charged, the heading: Finance Charge, followed by the amount in dollars and cents. The finance charge is to be set out separately from the contract amount.

(7)The heading: Description of the Project and Description of the Significant Materials to be Used and Equipment to be Installed, followed by a description of the project and a description of the significant materials to be used and equipment to be installed. For swimming pools, the project description required under this paragraph also shall include a plan and scale drawing showing the shape, size, dimensions, and the construction and equipment specifications.

(8)If a downpayment will be charged, the details of the downpayment shall be expressed in substantially the following form, and shall include the text of the notice as specified in subparagraph (C):

(A)The heading: Downpayment.

(B)A space where the actual downpayment appears.

(C)The following statement in at least 12-point boldface type:

THE DOWNPAYMENT MAY NOT EXCEED $1,000 OR 10 PERCENT OF THE CONTRACT PRICE, WHICHEVER IS LESS.

(9)If payments, other than the downpayment, are to be made before the project is completed, the details of these payments, known as progress payments, shall be expressed in substantially the following form, and shall include the text of the statement as specified in subparagraph (C):

(A)A schedule of progress payments shall be preceded by the heading: Schedule of Progress Payments.

(B)Each progress payment shall be stated in dollars and cents and specifically reference the amount of work or services to be performed and materials and equipment to be supplied.

(C)The section of the contract reserved for the progress payments shall include the following statement in at least 12-point boldface type:

The schedule of progress payments must specifically describe each phase of work, including the type and amount of work or services scheduled to be supplied in each phase, along with the amount of each proposed progress payment. IT IS AGAINST THE LAW FOR A CONTRACTOR TO COLLECT PAYMENT FOR WORK NOT YET COMPLETED, OR FOR MATERIALS NOT YET DELIVERED. HOWEVER, A CONTRACTOR MAY REQUIRE A DOWNPAYMENT.

(10)The contract shall address the commencement of work to be performed in substantially the following form:

(A)A statement that describes what constitutes substantial commencement of work under the contract.

(B)The heading: Approximate Start Date.

(C)The approximate date on which work will be commenced.

(11)The estimated completion date of the work shall be referenced in the contract in substantially the following form:

(A)The heading: Approximate Completion Date.

(B)The approximate date of completion.

(12)If applicable, the heading: List of Documents to be Incorporated into the Contract, followed by the list of documents incorporated into the contract.

(13)The heading: Note About Extra Work and Change Orders, followed by the following statement:

Extra Work and Change Orders become part of the contract once the order is prepared in writing and signed by the parties prior to the commencement of work covered by the new change order. The order must describe the scope of the extra work or change, the cost to be added or subtracted from the contract, and the effect the order will have on the schedule of progress payments.

(e)Except as provided in paragraph (8) of subdivision (a) of Section 7159.5, all of the following notices shall be provided to the owner as part of the contract form as specified or, if otherwise authorized under this subdivision, may be provided as an attachment to the contract:

(1)A notice concerning commercial general liability insurance. This notice may be provided as an attachment to the contract if the contract includes the following statement: A notice concerning commercial general liability insurance is attached to this contract. The notice shall include the heading Commercial General Liability Insurance (CGL), followed by whichever of the following statements is both relevant and correct:

(A)(The name on the license or This contractor) does not carry commercial general liability insurance.

(B)(The name on the license or This contractor) carries commercial general liability insurance written by (the insurance company). You may call (the insurance company) at ____ to check the contractors insurance coverage.

(C)(The name on the license or This contractor) is self-insured.

(D)(The name on the license or This contractor) is a limited liability company that carries liability insurance or maintains other security as required by law. You may call (the insurance company or trust company or bank) at ____ to check on the contractors insurance coverage or security.

(2)A notice concerning workers compensation insurance. This notice may be provided as an attachment to the contract if the contract includes the statement: A notice concerning workers compensation insurance is attached to this contract. The notice shall include the heading Workers Compensation Insurance followed by whichever of the following statements is correct:

(A)(The name on the license or This contractor) has no employees and is exempt from workers compensation requirements.

(B)(The name on the license or This contractor) carries workers compensation insurance for all employees.

(3)A notice that provides the buyer with the following information about the performance of extra or change-order work:

(A)A statement that the buyer may not require a contractor to perform extra or change-order work without providing written authorization prior to the commencement of work covered by the new change order.

(B)A statement informing the buyer that extra work or a change order is not enforceable against a buyer unless the change order also identifies all of the following in writing prior to the commencement of work covered by the new change order:

(i)The scope of work encompassed by the order.

(ii)The amount to be added or subtracted from the contract.

(iii)The effect the order will make in the progress payments or the completion date.

(C)A statement informing the buyer that the contractors failure to comply with the requirements of this paragraph does not preclude the recovery of compensation for work performed based upon legal or equitable remedies designed to prevent unjust enrichment.

(4)A notice with the heading Mechanics Lien Warning written as follows:

MECHANICS LIEN WARNING:

Anyone who helps improve your property, but who is not paid, may record what is called a mechanics lien on your property. A mechanics lien is a claim, like a mortgage or home equity loan, made against your property and recorded with the county recorder.

Even if you pay your contractor in full, unpaid subcontractors, suppliers, and laborers who helped to improve your property may record mechanics liens and sue you in court to foreclose the lien. If a court finds the lien is valid, you could be forced to pay twice or have a court officer sell your home to pay the lien. Liens can also affect your credit.

To preserve their right to record a lien, each subcontractor and material supplier must provide you with a document called a Preliminary Notice. This notice is not a lien. The purpose of the notice is to let you know that the person who sends you the notice has the right to record a lien on your property if they are not paid.

BE CAREFUL. The Preliminary Notice can be sent up to 20 days after the subcontractor starts work or the supplier provides material. This can be a big problem if you pay your contractor before you have received the Preliminary Notices.

You will not get Preliminary Notices from your prime contractor or from laborers who work on your project. The law assumes that you already know they are improving your property.

PROTECT YOURSELF FROM LIENS. You can protect yourself from liens by getting a list from your contractor of all the subcontractors and material suppliers that work on your project. Find out from your contractor when these subcontractors started work and when these suppliers delivered goods or materials. Then wait 20 days, paying attention to the Preliminary Notices you receive.

PAY WITH JOINT CHECKS. One way to protect yourself is to pay with a joint check. When your contractor tells you it is time to pay for the work of a subcontractor or supplier who has provided you with a Preliminary Notice, write a joint check payable to both the contractor and the subcontractor or material supplier.

For other ways to prevent liens, visit CSLBs internet website at www.cslb.ca.gov or call CSLB at 800-321-CSLB (2752).

REMEMBER, IF YOU DO NOTHING, YOU RISK HAVING A LIEN PLACED ON YOUR HOME. This can mean that you may have to pay twice, or face the forced sale of your home to pay what you owe.

(5)The following notice shall be provided in at least 12-point typeface:

Information about the Contractors State License Board (CSLB): CSLB is the state consumer protection agency that licenses and regulates construction contractors.

Contact CSLB for information about the licensed contractor you are considering, including information about disclosable complaints, disciplinary actions, and civil judgments that are reported to CSLB.

Use only licensed contractors. If you file a complaint against a licensed contractor within the legal deadline (usually four years), CSLB has authority to investigate the complaint. If you use an unlicensed contractor, CSLB may not be able to help you resolve your complaint. Your only remedy may be in civil court, and you may be liable for damages arising out of any injuries to the unlicensed contractor or the unlicensed contractors employees.

For more information:

Visit CSLBs internet website at www.cslb.ca.gov

Call CSLB at 800-321-CSLB (2752)

Write CSLB at P.O. Box 26000, Sacramento, CA 95826.

(6)(A)The notice set forth in subparagraph (B) and entitled Five-Day Right to Cancel, or entitled Seven-Day Right to Cancel for contracts with a senior citizen, shall be provided to the buyer unless the contract is:

(i)Negotiated at the contractors place of business.

(ii)Subject to the Seven-Day Right to Cancel, as set forth in paragraph (7).

(iii)Subject to licensure under the Alarm Company Act (Chapter 11.6 (commencing with Section 7590)), provided the alarm company licensee complies with Sections 1689.5, 1689.6, and 1689.7 of the Civil Code, as applicable.

(B)(i)Five-Day Right to Cancel

You, the buyer, have the right to cancel this contract within five business days. You may cancel by emailing, mailing, faxing, or delivering a written notice to the contractor at the contractors place of business by midnight of the fifth business day after you received a signed and dated copy of the contract that includes this notice. Include your name, your address, and the date you received the signed copy of the contract and this notice.

If you cancel, the contractor must return to you anything you paid within 10 days of receiving the notice of cancellation. For your part, you must make available to the contractor at your residence, in substantially as good condition as you received them, goods delivered to you under this contract or sale. Or, you may, if you wish, comply with the contractors instructions on how to return the goods at the contractors expense and risk. If you do make the goods available to the contractor and the contractor does not pick them up within 20 days of the date of your notice of cancellation, you may keep them without any further obligation. If you fail to make the goods available to the contractor, or if you agree to return the goods to the contractor and fail to do so, then you remain liable for performance of all obligations under the contract.

(ii)References to five and fifth in the notice set forth in clause (i) shall be changed to seven and seventh respectively, for a buyer who is a senior citizen.

(C)The notice required by this paragraph shall comply with all of the following:

(i)The text of the notice is at least 12-point boldface type.

(ii)The notice is in immediate proximity to a space reserved for the owners signature.

(iii)The owner acknowledges receipt of the notice by signing and dating the notice form in the signature space.

(iv)The notice is written in the same language, e.g., Spanish, as that principally used in any oral sales presentation.

(v)The notice may be attached to the contract if the contract includes, in at least 12-point boldface type, a checkbox with one of the following statements, as applicable:

(I)For a contract with a senior citizen: The law requires that the contractor give you a notice explaining your right to cancel. Initial the checkbox if the contractor has given you a Notice of the Seven-Day Right to Cancel.

(II)For all other contracts: The law requires that the contractor give you a notice explaining your right to cancel. Initial the checkbox if the contractor has given you a Notice of the Five-Day Right to Cancel.

(vi)(I)The notice shall be accompanied by a completed form in duplicate, captioned Notice of Cancellation, which also shall be attached to the agreement or offer to purchase and be easily detachable, and which shall contain the following statement written in the same language, e.g., Spanish, as used in the contract:

You may cancel this transaction, without any penalty or obligation, within five business days from the above date.

If you cancel, any property traded in, any payments made by you under the contract or sale, and any negotiable instrument executed by you will be returned within 10 days following receipt by the seller of your cancellation notice, and any security interest arising out of the transaction will be canceled.

If you cancel, you must make available to the seller at your residence, in substantially as good condition as when received, any goods delivered to you under this contract or sale, or you may, if you wish, comply with the instructions of the seller regarding the return shipment of the goods at the sellers expense and risk.

If you do make the goods available to the seller and the seller does not pick them up within 20 days of the date of your notice of cancellation, you may retain or dispose of the goods without any further obligation. If you fail to make the goods available to the seller, or if you agree to return the goods to the seller and fail to do so, then you remain liable for performance of all obligations under the contract.

(II)The reference to five in the statement set forth in subclause (I) shall be changed to seven for a buyer who is a senior citizen.

(7)(A)The following notice entitled Seven-Day Right to Cancel shall be provided to the buyer for any contract that is written for the repair or restoration of residential premises damaged by any sudden or catastrophic event for which a state of emergency has been declared by the President of the United States or the Governor, or for which a local emergency has been declared by the executive officer or governing body of any city, county, or city and county:

Seven-Day Right to Cancel

You, the buyer, have the right to cancel this contract within seven business days. You may cancel by emailing, mailing, faxing, or delivering a written notice to the contractor at the contractors place of business by midnight of the seventh business day after you received a signed and dated copy of the contract that includes this notice. Include your name, your address, and the date you received the signed copy of the contract and this notice.

If you cancel, the contractor must return to you anything you paid within 10 days of receiving the notice of cancellation. For your part, you must make available to the contractor at your residence, in substantially as good condition as you received them, goods delivered to you under this contract or sale. Or, you may, if you wish, comply with the contractors instructions on how to return the goods at the contractors expense and risk. If you do make the goods available to the contractor and the contractor does not pick them up within 20 days of the date of your notice of cancellation, you may keep them without any further obligation. If you fail to make the goods available to the contractor, or if you agree to return the goods to the contractor and fail to do so, then you remain liable for performance of all obligations under the contract.

(B)The Seven-Day Right to Cancel notice required by this subdivision shall comply with all of the following:

(i)The text of the notice is at least 12-point boldface type.

(ii)The notice is in immediate proximity to a space reserved for the owners signature.

(iii)The owner acknowledges receipt of the notice by signing and dating the notice form in the signature space.

(iv)The notice is written in the same language, e.g., Spanish, as that principally used in any oral sales presentation.

(v)The notice may be attached to the contract if the contract includes, in at least 12-point boldface type, a checkbox with the following statement: The law requires that the contractor give you a notice explaining your right to cancel. Initial the checkbox if the contractor has given you a Notice of the Seven-Day Right to Cancel.

(vi)The notice shall be accompanied by a completed form in duplicate, captioned Notice of Cancellation, which shall also be attached to the agreement or offer to purchase and be easily detachable, and which shall contain the following statement written in the same language, e.g., Spanish, as used in the contract:

You may cancel this transaction, without any penalty or obligation, within seven business days from the above date.

If you cancel, any property traded in, any payments made by you under the contract or sale, and any negotiable instrument executed by you will be returned within 10 days following receipt by the seller of your cancellation notice, and any security interest arising out of the transaction will be canceled.

If you cancel, you must make available to the seller at your residence, in substantially as good condition as when received, any goods delivered to you under this contract or sale, or you may, if you wish, comply with the instructions of the seller regarding the return shipment of the goods at the sellers expense and risk.

If you do make the goods available to the seller and the seller does not pick them up within 20 days of the date of your notice of cancellation, you may retain or dispose of the goods without any further obligation. If you fail to make the goods available to the seller, or if you agree to return the goods to the seller and fail to do so, then you remain liable for performance of all obligations under the contract.

(f)The five-day right to cancel added by the act that amended paragraph (6) of subdivision (e) shall apply to contracts entered into on or after January 1, 2021.

(g)The five-day and seven-day rights to cancel added by the act in the 202324 Regular Session of the Legislature that amended paragraph (6) of subdivision (e) shall apply to contracts entered into on or after January 1, 2025.

This section applies to all home improvement contracts, as defined in Section 7151.2, between an owner or tenant and a contractor, whether a general contractor or a specialty contractor, that is licensed or subject to be licensed pursuant to this chapter with regard to the transaction.

(a)Failure by the licensee or a person subject to be licensed under this chapter, or by their agent or salesperson, to comply with the following provisions is cause for discipline:

(1)The contract shall be in writing and shall include the agreed contract amount in dollars and cents. The contract amount shall include the entire cost of the contract, including profit, labor, and materials, but excluding finance charges.

(2)If there is a separate finance charge between the contractor and the person contracting for home improvement, the finance charge shall be set out separately from the contract amount.

(3)If a downpayment will be charged, the downpayment shall not exceed one thousand dollars ($1,000) or 10 percent of the contract amount, whichever amount is less.

(4)If, in addition to a downpayment, the contract provides for payments to be made prior to completion of the work, the contract shall include a schedule of payments in dollars and cents specifically referencing the amount of work or services to be performed and any materials and equipment to be supplied.

(5)Except for a downpayment, the contractor shall neither request nor accept payment that exceeds the value of the work performed or material delivered. The prohibition prescribed by this paragraph extends to advance payment in whole or in part from any lender or financier for the performance or sale of home improvement goods or services.

(6)Upon any payment by the person contracting for home improvement, and prior to any further payment being made, the contractor shall, if requested, obtain and furnish to the person a full and unconditional release from any potential lien claimant claim or mechanics lien authorized pursuant to Sections 8400 and 8404 of the Civil Code for any portion of the work for which payment has been made. The person contracting for home improvement may withhold all further payments until these releases are furnished.

(7)If the contract provides for a payment of a salespersons commission out of the contract price, that payment shall be made on a pro rata basis in proportion to the schedule of payments made to the contractor by the disbursing party in accordance with paragraph (4).

(8)A contractor furnishing a performance and payment bond, lien and completion bond, or a bond equivalent or joint control approved by the registrar covering full performance and payment is exempt from paragraphs (3), (4), and (5), and need not include, as part of the contract, the statement regarding the downpayment specified in subparagraph (C) of paragraph (8) of subdivision (d) of Section 7159, the details and statement regarding progress payments specified in paragraph (9) of subdivision (d) of Section 7159, or the Mechanics Lien Warning specified in paragraph (4) of subdivision (e) of Section 7159. A contractor furnishing these bonds, bond equivalents, or a joint control approved by the registrar may accept payment prior to completion. If the contract provides for a contractor to furnish joint control, the contractor shall not have any financial or other interest in the joint control. Notwithstanding any other law, a licensee shall be licensed in this state in an active status for not less than two years prior to submitting an Application for Approval of Blanket Performance and Payment Bond as provided in Section 858.2 of Title 16 of the California Code of Regulations as it read on January 1, 2016.

(9)The contractor shall not request or accept full payment from a finance lender, as defined in Section 22009 of the Financial Code, until the contractor has received a written confirmation from the owner acknowledging all of the following:

(A)The home improvement project has been completed in accordance with the contract.

(B)Final approval has been provided by all permitting agencies.

(C)The home improvement is operational.

(b)(1)A violation of paragraph (1), (3), or (5) of subdivision (a) by a licensee or a person subject to be licensed under this chapter, or by their agent or salesperson, is a misdemeanor punishable by a fine of not less than one hundred dollars ($100) nor more than five thousand dollars ($5,000), or by imprisonment in a county jail not exceeding one year, or by both that fine and imprisonment. If a violation occurs in a location damaged by a natural disaster for which a state of emergency is proclaimed by the Governor pursuant to Section 8625 of the Government Code or for which an emergency or major disaster is declared by the President of the United States, the court shall impose the maximum fine.

(2)(A)An indictment or information against a person who is not licensed but who is required to be licensed under this chapter shall be brought, or a criminal complaint filed, for a violation of this section, in accordance with paragraph (4) of subdivision (d) of Section 802 of the Penal Code, within four years from the date of the contract or, if the contract is not reduced to writing, from the date the buyer makes the first payment to the contractor.

(B)An indictment or information against a person who is licensed under this chapter shall be brought, or a criminal complaint filed, for a violation of this section, in accordance with paragraph (2) of subdivision (d) of Section 802 of the Penal Code, within two years from the date of the contract or, if the contract is not reduced to writing, from the date the buyer makes the first payment to the contractor.

(C)The limitations on actions in this subdivision shall not apply to any administrative action filed against a licensed contractor.

(c)(1)Any person who violates this section as part of a plan or scheme to defraud an owner or tenant of a residential or nonresidential structure, including a mobilehome or manufactured home, in connection with the offer or performance of repairs to the structure for damage caused by a natural disaster, shall be ordered by the court to make full restitution to the victim based on the persons ability to pay, defined as the overall capability of the defendant to reimburse the costs, or a portion of the costs, including consideration of, but not limited to, all of the following:

(A)The defendants present financial position.

(B)The defendants reasonably discernible future financial position, provided that the court shall not consider a period of more than one year from the date of the hearing for purposes of determining the reasonably discernible future financial position of the defendant.

(C)The likelihood that the defendant will be able to obtain employment within one year from the date of the hearing.

(D)Any other factor that may bear upon the defendants financial capability to reimburse the county for costs.

(2)In addition to full restitution, and imprisonment authorized by this section, the court may impose a fine of not less than five hundred dollars ($500) nor more than twenty-five thousand dollars ($25,000), based upon the defendants ability to pay. This subdivision applies to natural disasters for which a state of emergency is proclaimed by the Governor pursuant to Section 8625 of the Government Code, or for which an emergency or major disaster is declared by the President of the United States.

(d)This section shall become operative on July 1, 2021.

(a)(1)Except for a contract written pursuant to Section 7151.2 or 7159.10 of the Business and Professions Code, in addition to any other right to revoke an offer, the buyer has the right to cancel a home solicitation contract or offer until midnight of the fifth business day, or until midnight of the seventh business day if the buyer is a senior citizen, after the day on which the buyer signs an agreement or offer to purchase which complies with Section 1689.7.

(2)In addition to any other right to revoke an offer, the buyer has the right to cancel a home solicitation contract written pursuant to Section 7151.2 of the Business and Professions Code until midnight of the fifth business day, or until midnight of the seventh business day if the buyer is a senior citizen, after the buyer receives a signed and dated copy of the contract or offer to purchase that complies with Section 1689.7 of this code.

(3)(A)In addition to any other right to revoke an offer, the buyer has the right to cancel a home solicitation contract or offer to purchase written pursuant to Section 7159.10 of the Business and Professions Code, until the buyer receives a signed and dated copy of a service and repair contract that complies with the contract requirements specified in Section 7159.10 of the Business and Professions Code and the work commences.

(B)For any contract written pursuant to Section 7159.10 of the Business and Professions Code, or otherwise presented to the buyer as a service and repair contract, unless all of the conforming requirements listed under subdivision (a) of that section are met, the requirements set forth under Section 7159 of the Business and Professions Code shall be applicable, regardless of the aggregate contract price, including the right to cancel as set forth under this section.

(4)The five-day right to cancel added by the act that amended paragraphs (1) and (2) shall apply to contracts entered into, or offers to purchase conveyed, on or after January 1, 2021.

(5)The five-day and seven-day rights to cancel added by the act amending paragraphs (1) and (2) in the 202324 Regular Session of the Legislature shall apply to contracts entered into, or offers to purchase conveyed, on or after January 1, 2025.

(b)In addition to any other right to revoke an offer, any buyer has the right to cancel a home solicitation contract or offer for the purchase of a personal emergency response unit until midnight of the seventh business day after the day on which the buyer signs an agreement or offer to purchase which complies with Section 1689.7. This subdivision shall not apply to a personal emergency response unit installed with, and as part of, a home security alarm system subject to the Alarm Company Act (Chapter 11.6 (commencing with Section 7590) of Division 3 of the Business and Professions Code) which has two or more stationary protective devices used to enunciate an intrusion or fire and is installed by an alarm company operator operating under a current license issued pursuant to the Alarm Company Act, which shall instead be subject to subdivision (a).

(c)In addition to any other right to revoke an offer, a buyer has the right to cancel a home solicitation contract or offer for the repair or restoration of residential premises damaged by a disaster that was not void pursuant to Section 1689.14, until midnight of the seventh business day after the buyer signs and dates the contract unless the provisions of Section 1689.15 are applicable.

(d)Cancellation occurs when the buyer gives written notice of cancellation to the seller at the address specified in the agreement or offer.

(e)Notice of cancellation, if given by mail, is effective when deposited in the mail properly addressed with postage prepaid.

(f)Notice of cancellation given by the buyer need not take the particular form as provided with the contract or offer to purchase and, however expressed, is effective if it indicates the intention of the buyer not to be bound by the home solicitation contract or offer.

(g)Personal emergency response unit, for purposes of this section, means an in-home radio transmitter device or two-way radio device generally, but not exclusively, worn on a neckchain, wrist strap, or clipped to clothing, and connected to a telephone line through which a monitoring station is alerted of an emergency and emergency assistance is summoned.

(a)(1)Except for contracts written pursuant to Sections 7151.2 and 7159.10 of the Business and Professions Code, in a home solicitation contract or offer, the buyers agreement or offer to purchase shall be written in the same language, e.g., Spanish, as principally used in the oral sales presentation, shall be dated, shall be signed by the buyer, and except as provided in paragraph (2), shall contain in immediate proximity to the space reserved for the buyers signature, a conspicuous statement in a size equal to at least 10-point boldface type, as follows:

(A)For a buyer who is a senior citizen:You, the buyer, may cancel this transaction at any time prior to midnight of the seventh business day after the date of this transaction. See the attached notice of cancellation form for an explanation of this right.

(B)For all other buyers:You, the buyer, may cancel this transaction at any time prior to midnight of the fifth business day after the date of this transaction. See the attached notice of cancellation form for an explanation of this right.

(2)The statement required pursuant to this subdivision for a home solicitation contract or offer for the purchase of a personal emergency response unit, as defined in Section 1689.6, that is not installed with and as part of a home security alarm system subject to the Alarm Company Act (Chapter 11.6 (commencing with Section 7590) of Division 3 of the Business and Professions Code) that has two or more stationary protective devices used to enunciate an intrusion or fire and is installed by an alarm company operator operating under a current license issued pursuant to the Alarm Company Act, is as follows: You, the buyer, may cancel this transaction at any time prior to midnight of the seventh business day after the date of this transaction. See the attached notice of cancellation form for an explanation of this right.

(3)Except for contracts written pursuant to Sections 7151.2 and 7159.10 of the Business and Professions Code, the statement required pursuant to this subdivision for the repair or restoration of residential premises damaged by a disaster pursuant to subdivision (c) of Section 1689.6 is as follows:You, the buyer, may cancel this transaction at any time prior to midnight of the seventh business day after the date of this transaction. See the attached notice of cancellation form for an explanation of this right.

(4)(A)A home solicitation contract written pursuant to Section 7151.2 of the Business and Professions Code shall be written in the same language, e.g., Spanish, as principally used in the oral sales presentation. The contract, or an attachment to the contract that is subject to Section 7159 of the Business and Professions Code shall include in immediate proximity to the space reserved for the buyers signature, the following statement in a size equal to at least 12-point boldface type, which shall be dated and signed by the buyer:

Five-Day Right to Cancel

You, the buyer, have the right to cancel this contract within five business days. You may cancel by e-mailing, mailing, faxing, or delivering a written notice to the contractor at the contractors place of business by midnight of the fifth business day after you received a signed and dated copy of the contract that includes this notice. Include your name, your address, and the date you received the signed copy of the contract and this notice.

If you cancel, the contractor must return to you anything you paid within 10 days of receiving the notice of cancellation. For your part, you must make available to the contractor at your residence, in substantially as good condition as you received it, any goods delivered to you under this contract or sale. Or, you may, if you wish, comply with the contractors instructions on how to return the goods at the contractors expense and risk. If you do make the goods available to the contractor and the contractor does not pick them up within 20 days of the date of your notice of cancellation, you may keep them without any further obligation. If you fail to make the goods available to the contractor, or if you agree to return the goods to the contractor and fail to do so, then you remain liable for performance of all obligations under the contract.

(B)References to five and fifth in the statement set forth in subparagraph (A) shall be changed to seven and seventh, respectively, for a buyer who is a senior citizen.

(b)The agreement or offer to purchase shall contain on the first page, in a type size no smaller than that generally used in the body of the document, the following: (1) the name and address of the seller to which the notice is to be mailed, and (2) the date the buyer signed the agreement or offer to purchase.

(c)(1)Except for contracts written pursuant to Sections 7151.2 and 7159.10 of the Business and Professions Code, or except as provided in subdivision (d), the agreement or offer to purchase shall be accompanied by a completed form in duplicate, captioned Notice of Cancellation which shall be attached to the agreement or offer to purchase and be easily detachable, and which shall contain in type of at least 10-point the following statement written in the same language, e.g., Spanish, as used in the contract:

You may cancel this transaction, without any penalty or obligation, within five business days from the above date.

If you cancel, any property traded in, any payments made by you under the contract or sale, and any negotiable instrument executed by you will be returned within 10 days following receipt by the seller of your cancellation notice, and any security interest arising out of the transaction will be canceled.

If you cancel, you must make available to the seller at your residence, in substantially as good condition as when received, any goods delivered to you under this contract or sale, or you may, if you wish, comply with the instructions of the seller regarding the return shipment of the goods at the sellers expense and risk.

If you do make the goods available to the seller and the seller does not pick them up within 20 days of the date of your notice of cancellation, you may retain or dispose of the goods without any further obligation. If you fail to make the goods available to the seller, or if you agree to return the goods to the seller and fail to do so, then you remain liable for performance of all obligations under the contract.

(2)The reference to five in the statement set forth in paragraph (1) shall be changed to seven for a buyer who is a senior citizen.

(d)Any agreement or offer to purchase a personal emergency response unit, as defined in Section 1689.6, which is not installed with and as part of a home security alarm system subject to the Alarm Company Act which has two or more stationary protective devices used to enunciate an intrusion or fire and is installed by an alarm company operator operating under a current license issued pursuant to the Alarm Company Act, shall be subject to the requirements of subdivision (c), and shall be accompanied by the Notice of Cancellation required by subdivision (c), except that the first paragraph of that notice shall be deleted and replaced with the following paragraph:

You may cancel this transaction, without any penalty or obligation, within seven business days from the above date.

(e)A home solicitation contract written pursuant to Section 7151.2 of the Business and Professions Code for the repair or restoration of residential premises damaged by a disaster that is subject to subdivision (c) of Section 1689.6, shall be written in the same language, e.g., Spanish, as principally used in the oral sales presentation. The contract, or an attachment to the contract that is subject to Section 7159 of the Business and Professions Code shall include, in immediate proximity to the space reserved for the buyers signature, the following statement in a size equal to at least 12-point boldface type, which shall be signed and dated by the buyer:

Seven-Day Right to Cancel

You, the buyer, have the right to cancel this contract within seven business days. You may cancel by e-mailing, mailing, faxing, or delivering a written notice to the contractor at the contractors place of business by midnight of the seventh business day after you received a signed and dated copy of the contract that includes this notice. Include your name, your address, and the date you received the signed copy of the contract and this notice.

If you cancel, the contractor must return to you anything you paid within 10 days of receiving the notice of cancellation. For your part, you must make available to the contractor at your residence, in substantially as good condition as you received it, any goods delivered to you under this contract or sale. Or, you may, if you wish, comply with the contractors instructions on how to return the goods at the contractors expense and risk. If you do make the goods available to the contractor and the contractor does not pick them up within 20 days of the date of your notice of cancellation, you may keep them without any further obligation. If you fail to make the goods available to the contractor, or if you agree to return the goods to the contractor and fail to do so, then you remain liable for performance of all obligations under the contract.

(f)The seller shall provide the buyer with a copy of the contract or offer to purchase and the attached notice of cancellation, and shall inform the buyer orally of the buyers right to cancel and the requirement that cancellation be in writing, at the time the home solicitation contract or offer is executed.

(g)Until the seller has complied with this section the buyer may cancel the home solicitation contract or offer.

(h)Contract or sale as used in subdivision (c) means home solicitation contract or offer as defined by Section 1689.5.

(i)The five-day right to cancel added by the act that added subparagraph (A) to paragraph (1) and subparagraph (B) to paragraph (4) of subdivision (a), and paragraph (2) to subdivision (c) applies to contracts, or offers to purchase conveyed, entered into, on or after January 1, 2021.

(j)The five-day and seven-day rights to cancel added by the act in the 202324 Regular Session of the Legislature that amended subdivisions (a) and (c) apply to contracts entered into, or offers to purchase conveyed, on or after January 1, 2025.

Sections 1689.5, 1689.6, 1689.7, 1689.10, 1689.12, and 1689.14 do not apply to a contract that meets all of the following requirements:

(a)The contract is initiated by the buyer or the buyers agent or insurance representative.

(b)The contract is executed in connection with making of emergency or immediately necessary repairs that are necessary for the immediate protection of persons or real or personal property.

(c)(1)The buyer gives the seller a separate statement that is dated and signed that describes the situation that requires immediate remedy, and expressly acknowledges and waives the right to cancel the sale within five or seven business days, whichever applies.

(2)The waiver of the five-day right to cancel added by the act that amended paragraph (1) shall apply to contracts entered into, or offers to purchase conveyed, on or after January 1, 2021.

(3)The waiver of the five-day and seven-day rights to cancel added by the act in the 202324 Regular Session of the Legislature that amended paragraph (1) shall apply to contracts entered into, or offers to purchase conveyed, on or after January 1, 2025.

(a)Home improvement loan means a consumer loan issued by a finance lender subject to this division, the proceeds of which will be used by the borrower to finance a home improvement, as defined in Section 7151 of the Business and Professions Code, or issued disbursed to a contractor in connection with a home improvement solicitation contract, as defined in Section 1689.5 of the Civil Code, to finance a home improvement, as defined in Section 7151.2 7151 of the Business and Professions Code.

(a)(1)Before a consumer executes a contract for a home improvement loan to pay for a home improvement and before the right-to-cancel time period expires for a home improvement contract that is being financed by a home improvement loan, the finance lender shall do all of the following:

(A)Obtain a copy of the home improvement contract for the home improvement that is being financed by the home improvement loan.

(B)Complete and document a telephone call pursuant to paragraphs (2) and (3) to make oral confirmations about all of the following:

(i)All owners of the property have received a copy of the home improvement loan contract, with the key terms completed, the financing estimate and disclosure form required under the federal Truth in Lending Act, and the right to cancel form.

(ii)The key terms of the home improvement loan contract, in plain language, with the consumer on the call or to a verified authorized representative of the consumer on the call. The finance lender shall obtain acknowledgment from the consumer on the call to whom the oral confirmation is given.

(2)(A)At the commencement of the oral confirmation, the finance lender shall ask if the consumer on the call would prefer to communicate during the oral confirmation primarily in a language other than English that is specified in Section 1632 of the Civil Code. If the preferred language is supported by the finance lender, the oral confirmation shall be given in that primary language, except where the consumer on the call chooses to communicate through their own interpreter. If the preferred language is not supported and an interpreter is not chosen by the consumer on the call, the home improvement financing transaction loan contract shall not proceed.

(B)The oral confirmation required pursuant to subparagraph (A) shall include, but is not limited to, all of the following information:

(i)The consumer on the call has the right to have other persons present for the call, and an inquiry as to whether the consumer requests to exercise the right to include anyone else on the call. This shall occur at the onset of the call, after the determination of the preferred language of communication. The contractor or contractor salesperson, or both, for the home improvements being financed by the loan shall not be present during or participate in the call. A third party shall not be allowed to participate in the call unless expressly authorized by the consumer.

(ii)The consumer on the call is informed that they should review the home improvement loan and financing estimate and disclosure form with all other owners of the property.

(iii)The home improvements being installed that are being financed by the home improvement loan, including, but not limited to, the description of the home improvements as described in the home improvement contract.

(iv)The key terms of the home improvement loan.

(v)Confirmation of the consumers gross monthly household income and ability to pay the monthly payment amount and total cost.

(vi)The consumer understands that any estimates of cost savings from the home improvements are not guaranteed and may be unreliable.

(vii)Whether the property will be subject to a financing statement filing requirement, as specified in Section 9501 of the Commercial Code, during the term of the loan contract and that the obligations under the loan contract may be required to be paid in full before the property owner sells or refinances the property.

(3)The finance lender shall maintain a recording of the oral confirmation telephone call for at least five years after the loan term ends and shall make it available to the consumer upon request.

(b)If the oral confirmation required by this section was conducted primarily in a language other than English that is specified in Section 1632 of the Civil Code, the finance lender shall deliver in writing in the language used during the oral confirmation in the disclosures and contract or agreement required by law, including, but not limited to, all of the following:

(1)The loan contract.

(2)The right to cancel form.

(3)The financing estimate and disclosure form required under the federal Truth in Lending Act.

(c)As used in this section:

(1)Home improvement has the same meaning as defined in Section 7151 of the Business and Professions Code.

(2)Home improvement contract has the same meaning as defined in Section 7151.2 of the Business and Professions Code.

(3)Key terms means the terms of the home improvement loan, including what home improvements are being financed, the name of the contractor who will receive the loan proceeds, the loan term or period of time for repayment, total cost, monthly payment amounts, finance charge, and due dates, whether the amount of monthly payments due will change during the term of the loan, annual percentage rate of interest, how late fees may be incurred, how payments more than the minimum payment will be applied, whether there are any prepayment penalties, and when the first payment is due.

(4)Their own interpreter means a person, who is not a minor, who is able to speak fluently and read with full understanding both the English language and any of the languages specified in Section 1632 of the Civil Code, and who is not employed by, and whose services are not made available through, the finance lender or the contractor.

(a)A finance lender that engages in offering or providing a home improvement loan shall make available to the consumer or property owner, or both, upon request, information in the control or possession of the lender concerning the home improvement loan that was provided to the consumer to finance the home improvement contract, including information relating to any transaction, series of transactions, or to the account, including costs, charges, and payment history.

(b)A finance lender shall comply with the requirements of this section for any written request for information from a consumer that includes the name of the consumer, information that enables the lender to identify the consumers account, and states the information the consumer is requesting.

(c)A finance lender shall provide to the consumer or their verified authorized representative, upon request, any of the following documentation:

(1)Financing application executed by consumer.

(2)Financing agreement and disclosures, including all certificates, disclosures, and contracts associated with the account, and including all signed or initialed copies.

(3)A copy of the home improvement contract for the financed work, including all signed copies.

(4)Completion certificates or other evidence that performance of a home improvement is complete or satisfactorily concluded, including all signed copies.

(5)Electronic certificates, including verifications of all signatures that were obtained electronically, electronic signature envelopes, or audit trails.

(6)Documentation of all payments to contractor.

(7)Account history.

(8)Financing estimate and disclosures.

(9)An accounting from date of original transaction to the present.

(10)If secured by a financing statement, as described in Section 9501 of the Commercial Code, the finance lender shall provide that financing statement and the list of collateral or statement of account, or both, under Section 9210 of the Commercial Code.

(11)Recordings of all oral confirmation telephone calls with the consumer.

(d)A finance lender has a duty to maintain each of the records specified in subdivision (c) relating to any transaction for five years from the date that the financed amount is remitted to the contractor, or five years after the loan is repaid in full, whichever is later.

(e)A finance lender, by written notice provided to a consumer, may establish an address that a consumer must use to request information in accordance with the procedures in this section.

(f)No later than 30 business days after the finance lender receives the request for information, the finance lender shall do one of the following:

(1)Provide the consumer with the requested information and contact information, including a telephone number, for further assistance in writing.

(2)Conduct a reasonable search for the requested information and provide the consumer with a written notification that states that the lender has determined that the requested information is not available to the lender. That notification shall also identify the basis for the lenders determination, and provide contact information, including a telephone number, for further assistance.

(g)A finance lender, as a condition of responding to an information request, shall not charge a fee, or require a consumer to make any payment that may be owed on the consumers account, or impose any other requirement.

(h)As used in this section, consumer has the same meaning as defined in Section 4052.

(a)A finance lender who makes a home improvement loan shall not release funds to the home improvement contractor and shall not seek any payment, contractor, other than the downpayment allowed under Section 7159 of the Business and Professions Code, from the property owner until Code or those payments consistent with paragraphs (4) and (5) of subdivision (a) of Section 7159.5 of the Business and Professions Code, unless the property owner has certified orally, by means of a confirmation telephone call, and in writing, by means of a completion certificate call and a written confirmation signed by the property owner, that the home improvements contracted for which the payment is being made have been completed in accordance with the contract, have contract.

(b)Notwithstanding subdivision (a), no more than 85 percent of the funds shall be released to the home improvement contractor, and no payment shall be sought from the consumer, until the home improvements have been given final approval by all permitting agencies, and agencies and are operational. A solar energy system shall not be deemed complete operational until after the property owner confirms the utility supplying electricity has been connected to the solar energy system, the utility supplying electricity grants permission to operate the solar energy system, and the property owner confirms the solar energy system is functioning.

(c)As used in this section,solar energy system has the same meaning as defined in Section 7151 of the Business and Professions Code.

(a)This section applies to finance lenders who make home improvement loans.

(b)In any dispute arising out of a home improvement contract in which the consumer has also obtained a home improvement loan in excess of fifty dollars ($50), the consumer may assert against the finance lender all claims and defenses arising out of the transaction and relating to the contractors failure to resolve the dispute, if the consumer has made a good faith attempt to resolve the dispute with the contractor, irrespective of whether the contractor acted as the finance lenders agent within the meaning of Section 2295 of the Civil Code.

(c)If there is a dispute as described in subdivision (b), the consumer may withhold payment up to the amount of credit outstanding for the home improvement or services that gave rise to the dispute and any finance or other charges imposed on that amount.

(d)If, in accordance with subdivision (c), the consumer withholds payment of the amount of credit outstanding for the disputed transaction, the finance lender shall not report that amount as delinquent, regardless of the outcome of the dispute.

(a)(1)This section identifies the projects for which a home improvement contract is required, outlines the contract requirements, and lists the items that shall be included in the contract, or may be provided as an attachment.

(2)This section does not apply to service and repair contracts that are subject to Section 7159.10, if the contract for the applicable services complies with Sections 7159.10 to 7159.14, inclusive.

(3)This section does not apply to the sale, installation, and servicing of a fire alarm sold in conjunction with an alarm system, as defined in Section 7590.1, if all costs attributable to making the fire alarm system operable, including sale and installation costs, do not exceed five hundred dollars ($500), and the licensee complies with the requirements set forth in Section 7159.9.

(4)This section does not apply to any costs associated with monitoring a burglar or fire alarm system.

(5)Failure by the licensee, their agent or salesperson, or by a person subject to be licensed under this chapter, to provide the specified information, notices, and disclosures in the contract, or to otherwise fail to comply with any provision of this section, is cause for discipline.

(b)For purposes of this section, home improvement contract means an agreement, whether oral or written, or contained in one or more documents, between a contractor and an owner or between a contractor and a tenant, regardless of the number of residence or dwelling units contained in the building in which the tenant resides, if the work is to be performed in, to, or upon the residence or dwelling unit of the tenant, for the performance of a home improvement, as defined in Section 7151, and includes all labor, services, and materials to be furnished and performed thereunder, if the aggregate contract price specified in one or more improvement contracts, including all labor, services, and materials to be furnished by the contractor, exceeds five hundred dollars ($500). Home improvement contract also means an agreement, whether oral or written, or contained in one or more documents, between a salesperson, whether or not they are a home improvement salesperson, and an owner or a tenant, regardless of the number of residence or dwelling units contained in the building in which the tenant resides, which provides for the sale, installation, or furnishing of home improvement goods or services.

(c)In addition to the specific requirements listed under this section, every home improvement contract and any person subject to licensure under this chapter or their agent or salesperson shall comply with all of the following:

(1)The writing shall be legible.

(2)Any printed form shall be readable. Unless a larger typeface is specified in this article, text in any printed form shall be in at least 10-point typeface and the headings shall be in at least 10-point boldface type.

(3)(A)Before any work is started, the contractor shall give the buyer a copy of the contract signed and dated by both the contractor and the buyer. The buyers receipt of the copy of the contract initiates the buyers rights to cancel the contract pursuant to Sections 1689.5 to 1689.14, inclusive, of the Civil Code.

(B)The contract shall contain on the first page, in a typeface no smaller than that generally used in the body of the document, both of the following:

(i)The date the buyer signed the contract.

(ii)The name and address of the contractor to which the applicable Notice of Cancellation is to be mailed, immediately preceded by a statement advising the buyer that the Notice of Cancellation may be sent to the contractor at the address noted on the contract.

(4)The contract shall include a statement that, upon satisfactory payment being made for any portion of the work performed, the contractor, prior to any further payment being made, shall furnish to the person contracting for the home improvement or swimming pool work a full and unconditional release from any potential lien claimant claim or mechanics lien authorized pursuant to Sections 8400 and 8404 of the Civil Code for that portion of the work for which payment has been made.

(5)A change-order form for changes or extra work shall be incorporated into the contract and shall become part of the contract only if it is in writing and signed by the parties prior to the commencement of any work covered by a change order.

(6)The contract shall contain, in close proximity to the signatures of the owner and contractor, a notice stating that the owner or tenant has the right to require the contractor to have a performance and payment bond.

(7)If the contract provides for a contractor to furnish joint control, the contractor shall not have any financial or other interest in the joint control.

(8)The provisions of this section are not exclusive and do not relieve the contractor from compliance with any other applicable provision of law.

(d)A home improvement contract and any changes to the contract shall be in writing and signed by the parties to the contract prior to the commencement of work covered by the contract or an applicable change order and, except as provided in paragraph (8) of subdivision (a) of Section 7159.5, shall include or comply with all of the following:

(1)The name, business address, and license number of the contractor.

(2)If applicable, the name and registration number of the home improvement salesperson that solicited or negotiated the contract.

(3)The following heading on the contract form that identifies the type of contract in at least 10-point boldface type: Home Improvement.

(4)The following statement in at least 12-point boldface type: You are entitled to a completely filled in copy of this agreement, signed by both you and the contractor, before any work may be started.

(5)The heading: Contract Price, followed by the amount of the contract in dollars and cents.

(6)If a finance charge will be charged, the heading: Finance Charge, followed by the amount in dollars and cents. The finance charge is to be set out separately from the contract amount.

(7)The heading: Description of the Project and Description of the Significant Materials to be Used and Equipment to be Installed, followed by a description of the project and a description of the significant materials to be used and equipment to be installed. For swimming pools, the project description required under this paragraph also shall include a plan and scale drawing showing the shape, size, dimensions, and the construction and equipment specifications.

(8)If a downpayment will be charged, the details of the downpayment shall be expressed in substantially the following form, and shall include the text of the notice as specified in subparagraph (C):

(A)The heading: Downpayment.

(B)A space where the actual downpayment appears.

(C)The following statement in at least 12-point boldface type:

THE DOWNPAYMENT MAY NOT EXCEED $1,000 OR 10 PERCENT OF THE CONTRACT PRICE, WHICHEVER IS LESS.

(9)If payments, other than the downpayment, are to be made before the project is completed, the details of these payments, known as progress payments, shall be expressed in substantially the following form, and shall include the text of the statement as specified in subparagraph (C):

(A)A schedule of progress payments shall be preceded by the heading: Schedule of Progress Payments.

(B)Each progress payment shall be stated in dollars and cents and specifically reference the amount of work or services to be performed and materials and equipment to be supplied.

(C)The section of the contract reserved for the progress payments shall include the following statement in at least 12-point boldface type:

The schedule of progress payments must specifically describe each phase of work, including the type and amount of work or services scheduled to be supplied in each phase, along with the amount of each proposed progress payment. IT IS AGAINST THE LAW FOR A CONTRACTOR TO COLLECT PAYMENT FOR WORK NOT YET COMPLETED, OR FOR MATERIALS NOT YET DELIVERED. HOWEVER, A CONTRACTOR MAY REQUIRE A DOWNPAYMENT.

(10)The contract shall address the commencement of work to be performed in substantially the following form:

(A)A statement that describes what constitutes substantial commencement of work under the contract.

(B)The heading: Approximate Start Date.

(C)The approximate date on which work will be commenced.

(11)The estimated completion date of the work shall be referenced in the contract in substantially the following form:

(A)The heading: Approximate Completion Date.

(B)The approximate date of completion.

(12)If applicable, the heading: List of Documents to be Incorporated into the Contract, followed by the list of documents incorporated into the contract.

(13)The heading: Note About Extra Work and Change Orders, followed by the following statement:

Extra Work and Change Orders become part of the contract once the order is prepared in writing and signed by the parties prior to the commencement of work covered by the new change order. The order must describe the scope of the extra work or change, the cost to be added or subtracted from the contract, and the effect the order will have on the schedule of progress payments.

(e)Except as provided in paragraph (8) of subdivision (a) of Section 7159.5, all of the following notices shall be provided to the owner as part of the contract form as specified or, if otherwise authorized under this subdivision, may be provided as an attachment to the contract:

(1)A notice concerning commercial general liability insurance. This notice may be provided as an attachment to the contract if the contract includes the following statement: A notice concerning commercial general liability insurance is attached to this contract. The notice shall include the heading Commercial General Liability Insurance (CGL), followed by whichever of the following statements is both relevant and correct:

(A)(The name on the license or This contractor) does not carry commercial general liability insurance.

(B)(The name on the license or This contractor) carries commercial general liability insurance written by (the insurance company). You may call (the insurance company) at __________ ____ to check the contractors insurance coverage.

(C)(The name on the license or This contractor) is self-insured.

(D)(The name on the license or This contractor) is a limited liability company that carries liability insurance or maintains other security as required by law. You may call (the insurance company or trust company or bank) at ____ to check on the contractors insurance coverage or security.

(2)A notice concerning workers compensation insurance. This notice may be provided as an attachment to the contract if the contract includes the statement: A notice concerning workers compensation insurance is attached to this contract. The notice shall include the heading Workers Compensation Insurance followed by whichever of the following statements is correct:

(A)(The name on the license or This contractor) has no employees and is exempt from workers compensation requirements.

(B)(The name on the license or This contractor) carries workers compensation insurance for all employees.

(3)A notice that provides the buyer with the following information about the performance of extra or change-order work:

(A)A statement that the buyer may not require a contractor to perform extra or change-order work without providing written authorization prior to the commencement of work covered by the new change order.

(B)A statement informing the buyer that extra work or a change order is not enforceable against a buyer unless the change order also identifies all of the following in writing prior to the commencement of work covered by the new change order:

(i)The scope of work encompassed by the order.

(ii)The amount to be added or subtracted from the contract.

(iii)The effect the order will make in the progress payments or the completion date.

(C)A statement informing the buyer that the contractors failure to comply with the requirements of this paragraph does not preclude the recovery of compensation for work performed based upon legal or equitable remedies designed to prevent unjust enrichment.

(4)A notice with the heading Mechanics Lien Warning written as follows:

MECHANICS LIEN WARNING:

Anyone who helps improve your property, but who is not paid, may record what is called a mechanics lien on your property. A mechanics lien is a claim, like a mortgage or home equity loan, made against your property and recorded with the county recorder.

Even if you pay your contractor in full, unpaid subcontractors, suppliers, and laborers who helped to improve your property may record mechanics liens and sue you in court to foreclose the lien. If a court finds the lien is valid, you could be forced to pay twice or have a court officer sell your home to pay the lien. Liens can also affect your credit.

To preserve their right to record a lien, each subcontractor and material supplier must provide you with a document called a Preliminary Notice. This notice is not a lien. The purpose of the notice is to let you know that the person who sends you the notice has the right to record a lien on your property if they are not paid.

BE CAREFUL. The Preliminary Notice can be sent up to 20 days after the subcontractor starts work or the supplier provides material. This can be a big problem if you pay your contractor before you have received the Preliminary Notices.

You will not get Preliminary Notices from your prime contractor or from laborers who work on your project. The law assumes that you already know they are improving your property.

PROTECT YOURSELF FROM LIENS. You can protect yourself from liens by getting a list from your contractor of all the subcontractors and material suppliers that work on your project. Find out from your contractor when these subcontractors started work and when these suppliers delivered goods or materials. Then wait 20 days, paying attention to the Preliminary Notices you receive.

PAY WITH JOINT CHECKS. One way to protect yourself is to pay with a joint check. When your contractor tells you it is time to pay for the work of a subcontractor or supplier who has provided you with a Preliminary Notice, write a joint check payable to both the contractor and the subcontractor or material supplier.

For other ways to prevent liens, visit CSLBs internet website at www.cslb.ca.gov or call CSLB at 800-321-CSLB (2752).

REMEMBER, IF YOU DO NOTHING, YOU RISK HAVING A LIEN PLACED ON YOUR HOME. This can mean that you may have to pay twice, or face the forced sale of your home to pay what you owe.

(5)The following notice shall be provided in at least 12-point typeface:

Information about the Contractors State License Board (CSLB): CSLB is the state consumer protection agency that licenses and regulates construction contractors.

Contact CSLB for information about the licensed contractor you are considering, including information about disclosable complaints, disciplinary actions, and civil judgments that are reported to CSLB.

Use only licensed contractors. If you file a complaint against a licensed contractor within the legal deadline (usually four years), CSLB has authority to investigate the complaint. If you use an unlicensed contractor, CSLB may not be able to help you resolve your complaint. Your only remedy may be in civil court, and you may be liable for damages arising out of any injuries to the unlicensed contractor or the unlicensed contractors employees.

For more information:

Visit CSLBs internet website at www.cslb.ca.gov

Call CSLB at 800-321-CSLB (2752)

Write CSLB at P.O. Box 26000, Sacramento, CA 95826.

(6)(A)The notice set forth in subparagraph (B) and entitled Three-Day Five-Day Right to Cancel, or entitled Five-Day Seven-Day Right to Cancel for contracts with a senior citizen, shall be provided to the buyer unless the contract is:

(i)Negotiated at the contractors place of business.

(ii)Subject to the Seven-Day Right to Cancel, as set forth in paragraph (7).

(iii)Subject to licensure under the Alarm Company Act (Chapter 11.6 (commencing with Section 7590)), provided the alarm company licensee complies with Sections 1689.5, 1689.6, and 1689.7 of the Civil Code, as applicable.

(B)(i)Three-Day Five-Day Right to Cancel

You, the buyer, have the right to cancel this contract within three five business days. You may cancel by emailing, mailing, faxing, or delivering a written notice to the contractor at the contractors place of business by midnight of the third fifth business day after you received a signed and dated copy of the contract that includes this notice. Include your name, your address, and the date you received the signed copy of the contract and this notice.

If you cancel, the contractor must return to you anything you paid within 10 days of receiving the notice of cancellation. For your part, you must make available to the contractor at your residence, in substantially as good condition as you received them, goods delivered to you under this contract or sale. Or, you may, if you wish, comply with the contractors instructions on how to return the goods at the contractors expense and risk. If you do make the goods available to the contractor and the contractor does not pick them up within 20 days of the date of your notice of cancellation, you may keep them without any further obligation. If you fail to make the goods available to the contractor, or if you agree to return the goods to the contractor and fail to do so, then you remain liable for performance of all obligations under the contract.

(ii)References to three five and third fifth in the notice set forth in clause (i) shall be changed to five seven and fifth, seventh respectively, for a buyer who is a senior citizen.

(C)The notice required by this paragraph shall comply with all of the following:

(i)The text of the notice is at least 12-point boldface type.

(ii)The notice is in immediate proximity to a space reserved for the owners signature.

(iii)The owner acknowledges receipt of the notice by signing and dating the notice form in the signature space.

(iv)The notice is written in the same language, e.g., Spanish, as that principally used in any oral sales presentation.

(v)The notice may be attached to the contract if the contract includes, in at least 12-point boldface type, a checkbox with one of the following statements, as applicable:

(I)For a contract with a senior citizen: The law requires that the contractor give you a notice explaining your right to cancel. Initial the checkbox if the contractor has given you a Notice of the Five-Day Seven-Day Right to Cancel.

(II)For all other contracts: The law requires that the contractor give you a notice explaining your right to cancel. Initial the checkbox if the contractor has given you a Notice of the Three-Day Five-Day Right to Cancel.

(vi)(I)The notice shall be accompanied by a completed form in duplicate, captioned Notice of Cancellation, which also shall be attached to the agreement or offer to purchase and be easily detachable, and which shall contain the following statement written in the same language, e.g., Spanish, as used in the contract:

You may cancel this transaction, without any penalty or obligation, within three five business days from the above date.

If you cancel, any property traded in, any payments made by you under the contract or sale, and any negotiable instrument executed by you will be returned within 10 days following receipt by the seller of your cancellation notice, and any security interest arising out of the transaction will be canceled.

If you cancel, you must make available to the seller at your residence, in substantially as good condition as when received, any goods delivered to you under this contract or sale, or you may, if you wish, comply with the instructions of the seller regarding the return shipment of the goods at the sellers expense and risk.

If you do make the goods available to the seller and the seller does not pick them up within 20 days of the date of your notice of cancellation, you may retain or dispose of the goods without any further obligation. If you fail to make the goods available to the seller, or if you agree to return the goods to the seller and fail to do so, then you remain liable for performance of all obligations under the contract.

(II)The reference to three five in the statement set forth in subclause (I) shall be changed to five seven for a buyer who is a senior citizen.

(7)(A)The following notice entitled Seven-Day Right to Cancel shall be provided to the buyer for any contract that is written for the repair or restoration of residential premises damaged by any sudden or catastrophic event for which a state of emergency has been declared by the President of the United States or the Governor, or for which a local emergency has been declared by the executive officer or governing body of any city, county, or city and county:

Seven-Day Right to Cancel

You, the buyer, have the right to cancel this contract within seven business days. You may cancel by emailing, mailing, faxing, or delivering a written notice to the contractor at the contractors place of business by midnight of the seventh business day after you received a signed and dated copy of the contract that includes this notice. Include your name, your address, and the date you received the signed copy of the contract and this notice.

If you cancel, the contractor must return to you anything you paid within 10 days of receiving the notice of cancellation. For your part, you must make available to the contractor at your residence, in substantially as good condition as you received them, goods delivered to you under this contract or sale. Or, you may, if you wish, comply with the contractors instructions on how to return the goods at the contractors expense and risk. If you do make the goods available to the contractor and the contractor does not pick them up within 20 days of the date of your notice of cancellation, you may keep them without any further obligation. If you fail to make the goods available to the contractor, or if you agree to return the goods to the contractor and fail to do so, then you remain liable for performance of all obligations under the contract.

(B)The Seven-Day Right to Cancel notice required by this subdivision shall comply with all of the following:

(i)The text of the notice is at least 12-point boldface type.

(ii)The notice is in immediate proximity to a space reserved for the owners signature.

(iii)The owner acknowledges receipt of the notice by signing and dating the notice form in the signature space.

(iv)The notice is written in the same language, e.g., Spanish, as that principally used in any oral sales presentation.

(v)The notice may be attached to the contract if the contract includes, in at least 12-point boldface type, a checkbox with the following statement: The law requires that the contractor give you a notice explaining your right to cancel. Initial the checkbox if the contractor has given you a Notice of the Seven-Day Right to Cancel.

(vi)The notice shall be accompanied by a completed form in duplicate, captioned Notice of Cancellation, which shall also be attached to the agreement or offer to purchase and be easily detachable, and which shall contain the following statement written in the same language, e.g., Spanish, as used in the contract:

You may cancel this transaction, without any penalty or obligation, within seven business days from the above date.

If you cancel, any property traded in, any payments made by you under the contract or sale, and any negotiable instrument executed by you will be returned within 10 days following receipt by the seller of your cancellation notice, and any security interest arising out of the transaction will be canceled.

If you cancel, you must make available to the seller at your residence, in substantially as good condition as when received, any goods delivered to you under this contract or sale, or you may, if you wish, comply with the instructions of the seller regarding the return shipment of the goods at the sellers expense and risk.

If you do make the goods available to the seller and the seller does not pick them up within 20 days of the date of your notice of cancellation, you may retain or dispose of the goods without any further obligation. If you fail to make the goods available to the seller, or if you agree to return the goods to the seller and fail to do so, then you remain liable for performance of all obligations under the contract.

(f)The five-day right to cancel added by the act that amended paragraph (6) of subdivision (e) shall apply to contracts entered into on or after January 1, 2021.

This section applies to all home improvement contracts, as defined in Section 7151.2, between an owner or tenant and a contractor, whether a general contractor or a specialty contractor, that is licensed or subject to be licensed pursuant to this chapter with regard to the transaction.

(a)Failure by the licensee or a person subject to be licensed under this chapter, or by their agent or salesperson, to comply with the following provisions is cause for discipline:

(1)The contract shall be in writing and shall include the agreed contract amount in dollars and cents. The contract amount shall include the entire cost of the contract, including profit, labor, and materials, but excluding finance charges.

(2)If there is a separate finance charge between the contractor and the person contracting for home improvement, the finance charge shall be set out separately from the contract amount.

(3)If a downpayment will be charged, the downpayment shall not exceed one thousand dollars ($1,000) or 10 percent of the contract amount, whichever amount is less.

(4)If, in addition to a downpayment, the contract provides for payments to be made prior to completion of the work, the contract shall include a schedule of payments in dollars and cents specifically referencing the amount of work or services to be performed and any materials and equipment to be supplied.

(5)Except for a downpayment, the contractor shall neither request nor accept payment that exceeds the value of the work performed or material delivered. The prohibition prescribed by this paragraph extends to advance payment in whole or in part from any lender or financier for the performance or sale of home improvement goods or services.

(6)Upon any payment by the person contracting for home improvement, and prior to any further payment being made, the contractor shall, if requested, obtain and furnish to the person a full and unconditional release from any potential lien claimant claim or mechanics lien authorized pursuant to Sections 8400 and 8404 of the Civil Code for any portion of the work for which payment has been made. The person contracting for home improvement may withhold all further payments until these releases are furnished.

(7)If the contract provides for a payment of a salespersons commission out of the contract price, that payment shall be made on a pro rata basis in proportion to the schedule of payments made to the contractor by the disbursing party in accordance with paragraph (4).

(8)A contractor furnishing a performance and payment bond, lien and completion bond, or a bond equivalent or joint control approved by the registrar covering full performance and payment is exempt from paragraphs (3), (4), and (5), and need not include, as part of the contract, the statement regarding the downpayment specified in subparagraph (C) of paragraph (8) of subdivision (d) of Section 7159, the details and statement regarding progress payments specified in paragraph (9) of subdivision (d) of Section 7159, or the Mechanics Lien Warning specified in paragraph (4) of subdivision (e) of Section 7159. A contractor furnishing these bonds, bond equivalents, or a joint control approved by the registrar may accept payment prior to completion. If the contract provides for a contractor to furnish joint control, the contractor shall not have any financial or other interest in the joint control. Notwithstanding any other law, a licensee shall be licensed in this state in an active status for not less than two years prior to submitting an Application for Approval of Blanket Performance and Payment Bond as provided in Section 858.2 of Title 16 of the California Code of Regulations as it read on January 1, 2016.

(b)(1)A violation of paragraph (1), (3), or (5) of subdivision (a) by a licensee or a person subject to be licensed under this chapter, or by their agent or salesperson, is a misdemeanor punishable by a fine of not less than one hundred dollars ($100) nor more than five thousand dollars ($5,000), or by imprisonment in a county jail not exceeding one year, or by both that fine and imprisonment. If a violation occurs in a location damaged by a natural disaster for which a state of emergency is proclaimed by the Governor pursuant to Section 8625 of the Government Code or for which an emergency or major disaster is declared by the President of the United States, the court shall impose the maximum fine.

(2)(A)An indictment or information against a person who is not licensed but who is required to be licensed under this chapter shall be brought, or a criminal complaint filed, for a violation of this section, in accordance with paragraph (4) of subdivision (d) of Section 802 of the Penal Code, within four years from the date of the contract or, if the contract is not reduced to writing, from the date the buyer makes the first payment to the contractor.

(B)An indictment or information against a person who is licensed under this chapter shall be brought, or a criminal complaint filed, for a violation of this section, in accordance with paragraph (2) of subdivision (d) of Section 802 of the Penal Code, within two years from the date of the contract or, if the contract is not reduced to writing, from the date the buyer makes the first payment to the contractor.

(C)The limitations on actions in this subdivision shall not apply to any administrative action filed against a licensed contractor.

(c)(1)Any person who violates this section as part of a plan or scheme to defraud an owner or tenant of a residential or nonresidential structure, including a mobilehome or manufactured home, in connection with the offer or performance of repairs to the structure for damage caused by a natural disaster, shall be ordered by the court to make full restitution to the victim based on the persons ability to pay, defined as the overall capability of the defendant to reimburse the costs, or a portion of the costs, including consideration of, but not limited to, all of the following:

(A)The defendants present financial position.

(B)The defendants reasonably discernible future financial position, provided that the court shall not consider a period of more than one year from the date of the hearing for purposes of determining the reasonably discernible future financial position of the defendant.

(C)The likelihood that the defendant will be able to obtain employment within one year from the date of the hearing.

(D)Any other factor that may bear upon the defendants financial capability to reimburse the county for costs.

(2)In addition to full restitution, and imprisonment authorized by this section, the court may impose a fine of not less than five hundred dollars ($500) nor more than twenty-five thousand dollars ($25,000), based upon the defendants ability to pay. This subdivision applies to natural disasters for which a state of emergency is proclaimed by the Governor pursuant to Section 8625 of the Government Code, or for which an emergency or major disaster is declared by the President of the United States.

(d)This section shall become operative on July 1, 2021.

(a)(1)Except for a contract written pursuant to Section 7151.2 or 7159.10 of the Business and Professions Code, in addition to any other right to revoke an offer, the buyer has the right to cancel a home solicitation contract or offer until midnight of the third fifth business day, or until midnight of the fifth seventh business day if the buyer is a senior citizen, after the day on which the buyer signs an agreement or offer to purchase which complies with Section 1689.7.

(2)In addition to any other right to revoke an offer, the buyer has the right to cancel a home solicitation contract written pursuant to Section 7151.2 of the Business and Professions Code until midnight of the third fifth business day, or until midnight of the fifth seventh business day if the buyer is a senior citizen, after the buyer receives a signed and dated copy of the contract or offer to purchase that complies with Section 1689.7 of this code.

(3)(A)In addition to any other right to revoke an offer, the buyer has the right to cancel a home solicitation contract or offer to purchase written pursuant to Section 7159.10 of the Business and Professions Code, until the buyer receives a signed and dated copy of a service and repair contract that complies with the contract requirements specified in Section 7159.10 of the Business and Professions Code and the work commences.

(B)For any contract written pursuant to Section 7159.10 of the Business and Professions Code, or otherwise presented to the buyer as a service and repair contract, unless all of the conforming requirements listed under subdivision (a) of that section are met, the requirements set forth under Section 7159 of the Business and Professions Code shall be applicable, regardless of the aggregate contract price, including the right to cancel as set forth under this section.

(4)The five-day right to cancel added by the act that amended paragraphs (1) and (2) shall apply to contracts entered into, or offers to purchase conveyed, on or after January 1, 2021.

(b)In addition to any other right to revoke an offer, any buyer has the right to cancel a home solicitation contract or offer for the purchase of a personal emergency response unit until midnight of the seventh business day after the day on which the buyer signs an agreement or offer to purchase which complies with Section 1689.7. This subdivision shall not apply to a personal emergency response unit installed with, and as part of, a home security alarm system subject to the Alarm Company Act (Chapter 11.6 (commencing with Section 7590) of Division 3 of the Business and Professions Code) which has two or more stationary protective devices used to enunciate an intrusion or fire and is installed by an alarm company operator operating under a current license issued pursuant to the Alarm Company Act, which shall instead be subject to subdivision (a).

(c)In addition to any other right to revoke an offer, a buyer has the right to cancel a home solicitation contract or offer for the repair or restoration of residential premises damaged by a disaster that was not void pursuant to Section 1689.14, until midnight of the seventh business day after the buyer signs and dates the contract unless the provisions of Section 1689.15 are applicable.

(d)Cancellation occurs when the buyer gives written notice of cancellation to the seller at the address specified in the agreement or offer.

(e)Notice of cancellation, if given by mail, is effective when deposited in the mail properly addressed with postage prepaid.

(f)Notice of cancellation given by the buyer need not take the particular form as provided with the contract or offer to purchase and, however expressed, is effective if it indicates the intention of the buyer not to be bound by the home solicitation contract or offer.

(g)Personal emergency response unit, for purposes of this section, means an in-home radio transmitter device or two-way radio device generally, but not exclusively, worn on a neckchain, wrist strap, or clipped to clothing, and connected to a telephone line through which a monitoring station is alerted of an emergency and emergency assistance is summoned.

(a)(1)Except for contracts written pursuant to Sections 7151.2 and 7159.10 of the Business and Professions Code, in a home solicitation contract or offer, the buyers agreement or offer to purchase shall be written in the same language, e.g., Spanish, as principally used in the oral sales presentation, shall be dated, shall be signed by the buyer, and except as provided in paragraph (2), shall contain in immediate proximity to the space reserved for the buyers signature, a conspicuous statement in a size equal to at least 10-point boldface type, as follows:

(A)For a buyer who is a senior citizen:You, the buyer, may cancel this transaction at any time prior to midnight of the fifth seventh business day after the date of this transaction. See the attached notice of cancellation form for an explanation of this right.

(B)For all other buyers:You, the buyer, may cancel this transaction at any time prior to midnight of the third fifth business day after the date of this transaction. See the attached notice of cancellation form for an explanation of this right.

(2)The statement required pursuant to this subdivision for a home solicitation contract or offer for the purchase of a personal emergency response unit, as defined in Section 1689.6, that is not installed with and as part of a home security alarm system subject to the Alarm Company Act (Chapter 11.6 (commencing with Section 7590) of Division 3 of the Business and Professions Code) that has two or more stationary protective devices used to enunciate an intrusion or fire and is installed by an alarm company operator operating under a current license issued pursuant to the Alarm Company Act, is as follows: You, the buyer, may cancel this transaction at any time prior to midnight of the seventh business day after the date of this transaction. See the attached notice of cancellation form for an explanation of this right.

(3)Except for contracts written pursuant to Sections 7151.2 and 7159.10 of the Business and Professions Code, the statement required pursuant to this subdivision for the repair or restoration of residential premises damaged by a disaster pursuant to subdivision (c) of Section 1689.6 is as follows:You, the buyer, may cancel this transaction at any time prior to midnight of the seventh business day after the date of this transaction. See the attached notice of cancellation form for an explanation of this right.

(4)(A)A home solicitation contract written pursuant to Section 7151.2 of the Business and Professions Code shall be written in the same language, e.g., Spanish, as principally used in the oral sales presentation. The contract, or an attachment to the contract that is subject to Section 7159 of the Business and Professions Code shall include in immediate proximity to the space reserved for the buyers signature, the following statement in a size equal to at least 12-point boldface type, which shall be dated and signed by the buyer:

Three-Day Five-Day Right to Cancel

You, the buyer, have the right to cancel this contract within three five business days. You may cancel by e-mailing, mailing, faxing, or delivering a written notice to the contractor at the contractors place of business by midnight of the third fifth business day after you received a signed and dated copy of the contract that includes this notice. Include your name, your address, and the date you received the signed copy of the contract and this notice.

If you cancel, the contractor must return to you anything you paid within 10 days of receiving the notice of cancellation. For your part, you must make available to the contractor at your residence, in substantially as good condition as you received it, any goods delivered to you under this contract or sale. Or, you may, if you wish, comply with the contractors instructions on how to return the goods at the contractors expense and risk. If you do make the goods available to the contractor and the contractor does not pick them up within 20 days of the date of your notice of cancellation, you may keep them without any further obligation. If you fail to make the goods available to the contractor, or if you agree to return the goods to the contractor and fail to do so, then you remain liable for performance of all obligations under the contract.

(B)References to three five and third fifth in the statement set forth in subparagraph (A) shall be changed to five seven and fifth, seventh, respectively, for a buyer who is a senior citizen.

(b)The agreement or offer to purchase shall contain on the first page, in a type size no smaller than that generally used in the body of the document, the following: (1) the name and address of the seller to which the notice is to be mailed, and (2) the date the buyer signed the agreement or offer to purchase.

(c)(1)Except for contracts written pursuant to Sections 7151.2 and 7159.10 of the Business and Professions Code, or except as provided in subdivision (d), the agreement or offer to purchase shall be accompanied by a completed form in duplicate, captioned Notice of Cancellation which shall be attached to the agreement or offer to purchase and be easily detachable, and which shall contain in type of at least 10-point the following statement written in the same language, e.g., Spanish, as used in the contract:

You may cancel this transaction, without any penalty or obligation, within three five business days from the above date.

If you cancel, any property traded in, any payments made by you under the contract or sale, and any negotiable instrument executed by you will be returned within 10 days following receipt by the seller of your cancellation notice, and any security interest arising out of the transaction will be canceled.

If you cancel, you must make available to the seller at your residence, in substantially as good condition as when received, any goods delivered to you under this contract or sale, or you may, if you wish, comply with the instructions of the seller regarding the return shipment of the goods at the sellers expense and risk.

If you do make the goods available to the seller and the seller does not pick them up within 20 days of the date of your notice of cancellation, you may retain or dispose of the goods without any further obligation. If you fail to make the goods available to the seller, or if you agree to return the goods to the seller and fail to do so, then you remain liable for performance of all obligations under the contract.

(2)The reference to three five in the statement set forth in paragraph (1) shall be changed to five seven for a buyer who is a senior citizen.

(d)Any agreement or offer to purchase a personal emergency response unit, as defined in Section 1689.6, which is not installed with and as part of a home security alarm system subject to the Alarm Company Act which has two or more stationary protective devices used to enunciate an intrusion or fire and is installed by an alarm company operator operating under a current license issued pursuant to the Alarm Company Act, shall be subject to the requirements of subdivision (c), and shall be accompanied by the Notice of Cancellation required by subdivision (c), except that the first paragraph of that notice shall be deleted and replaced with the following paragraph:

You may cancel this transaction, without any penalty or obligation, within seven business days from the above date.

(e)A home solicitation contract written pursuant to Section 7151.2 of the Business and Professions Code for the repair or restoration of residential premises damaged by a disaster that is subject to subdivision (c) of Section 1689.6, shall be written in the same language, e.g., Spanish, as principally used in the oral sales presentation. The contract, or an attachment to the contract that is subject to Section 7159 of the Business and Professions Code shall include, in immediate proximity to the space reserved for the buyers signature, the following statement in a size equal to at least 12-point boldface type, which shall be signed and dated by the buyer:

Seven-Day Right to Cancel

You, the buyer, have the right to cancel this contract within seven business days. You may cancel by e-mailing, mailing, faxing, or delivering a written notice to the contractor at the contractors place of business by midnight of the seventh business day after you received a signed and dated copy of the contract that includes this notice. Include your name, your address, and the date you received the signed copy of the contract and this notice.

If you cancel, the contractor must return to you anything you paid within 10 days of receiving the notice of cancellation. For your part, you must make available to the contractor at your residence, in substantially as good condition as you received it, any goods delivered to you under this contract or sale. Or, you may, if you wish, comply with the contractors instructions on how to return the goods at the contractors expense and risk. If you do make the goods available to the contractor and the contractor does not pick them up within 20 days of the date of your notice of cancellation, you may keep them without any further obligation. If you fail to make the goods available to the contractor, or if you agree to return the goods to the contractor and fail to do so, then you remain liable for performance of all obligations under the contract.

(f)The seller shall provide the buyer with a copy of the contract or offer to purchase and the attached notice of cancellation, and shall inform the buyer orally of the buyers right to cancel and the requirement that cancellation be in writing, at the time the home solicitation contract or offer is executed.

(g)Until the seller has complied with this section the buyer may cancel the home solicitation contract or offer.

(h)Contract or sale as used in subdivision (c) means home solicitation contract or offer as defined by Section 1689.5.

(i)The five-day right to cancel added by the act that added subparagraph (A) to paragraph (1) and subparagraph (B) to paragraph (4) of subdivision (a), and paragraph (2) to subdivision (c) applies to contracts, or offers to purchase conveyed, entered into, on or after January 1, 2021.

Sections 1689.5, 1689.6, 1689.7, 1689.10, 1689.12, and 1689.14 do not apply to a contract that meets all of the following requirements:

(a)The contract is initiated by the buyer or the buyers agent or insurance representative.

(b)The contract is executed in connection with making of emergency or immediately necessary repairs that are necessary for the immediate protection of persons or real or personal property.

(c)(1)The buyer gives the seller a separate statement that is dated and signed that describes the situation that requires immediate remedy, and expressly acknowledges and waives the right to cancel the sale within three, five, five or seven business days, whichever applies.

(2)The waiver of the five-day right to cancel added by the act that amended paragraph (1) shall apply to contracts entered into, or offers to purchase conveyed, on or after January 1, 2021.

(a)No A person shall not engage in the business of a finance lender or broker without obtaining a license from the commissioner.

(b)Every A licensee engaging in the business of making or brokering residential mortgage loans shall require that every mortgage loan originator employed or compensated by that licensee obtains and maintains a mortgage loan originator license from the commissioner under this division or Division 20 (commencing with Section 50000), or has first obtained a license endorsement from the Commissioner of Real Estate Real Estate Commissioner pursuant to Article 2.1 (commencing with Section 10166.01) of Chapter 3 of Part 1 of Division 4 of the Business and Professions Code.

(c)A finance lender or broker shall not employ a mortgage loan originator whose license or license endorsement has lapsed.

(d)A finance lender or broker may not make or broker a residential mortgage loan unless that loan is offered by, negotiated by, or applied for through a licensed mortgage loan originator.

(e)Every licensee engaged in the business of making or brokering residential mortgage loans and every mortgage loan originator licensed under this division shall register with and maintain a valid unique identifier issued by the Nationwide Mortgage Licensing System and Registry.

(f)An individual shall not engage in the business of a mortgage loan originator with respect to any dwelling located in this state without first obtaining and maintaining annually a license in accordance with the requirements of this division and any rules promulgated by the commissioner under this chapter.

(g)A registered mortgage loan originator, as defined in subdivision (c) of Section 22013, is exempt from licensure under this section when he or she is employed by:

(1)A depository institution.

(2)A subsidiary of a depository institution that is owned and controlled by a depository institution and regulated by a federal banking agency.

(3)An institution regulated by the Farm Credit Administration.